Fairfield Connecticut Building Expert Directory

Tips for Contractors Who Want to Help Rebuild After the California Wildfires

November 02, 2017 — Garret Murai - California Construction Law Blog
I received a call from one of my contractor clients this past week to see what he could do to help those affected by California’s North Bay fires. The North Bay fires are the deadliest and most destructive wildfires in California’s history. To date, the fires have claimed 42 lives, burned more than 200,000 acres of land, destroyed an estimated 8,400 structures and likely damaged tens of thousands more. By comparison, the state’s second most deadly wildfire, the Oakland Hills fire of 1991, claimed the lives of 25 people, burned 1,600 acres of land, and destroyed 2,900 structures. Rebuilding costs for the North Bay fires, according to the California Insurance Commissioner, are expected to top $1 billion. For those with insurance, insurance experts say that the rebuilding process can take two years or more for those whose homes and businesses were destroyed. For those whose homes and businesses were fortunate enough only to be damaged, rebuilding efforts are already underway. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

US-Mexico Border Wall Bids Include Tourist Attraction, Solar Panels

April 05, 2017 — Engineering News-Record
SAN DIEGO (AP) — Tuesday was the deadline for companies to propose designs for President Donald Trump's border wall with Mexico . U.S. Customs and Border Protection will ask several of the bidders to build prototypes in San Diego . The government won't identify companies until contracts are awarded around June 1 — and even then, only the winners — but some bidders released plans on their own. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

What Construction Contractors Should Know About the California Government Claims Act

May 28, 2024 — Garret Murai - California Construction Law Blog
If you work on state or local public works projects in California you should have at least a basic understanding of the Government Claims Act formerly known as the Tort Claims Act (Govt. Code §§ 900 et seq.). In the event of a dispute with a public entity, the Government Claims Act will usually apply, absent contractual provisions providing otherwise (Govt. Code §§930, 930.2) (e.g., in a construction contract), and requires that a “claim” first be presented to a “public entity” before a claimant files a lawsuit against the public entity. Failure to comply with the Government Claims Act can serve as a bar to maintaining a lawsuit against a public entity. What types of claims does the Government Claims Act apply to? The Government Claims Act broadly applies to most claims against state and local public entities. This is not limited to construction projects and includes all claims for “money or damage” arising from death, personal injury, breach of contract, and damage to real and personal property, wrongful death, or breach of contract. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Repair of Fractured Girders Complete at Shuttered Salesforce Transit Center

July 22, 2019 — Nadine M. Post - Engineering News-Record
The repair of two fractured girders spanning Fremont Street and the reinforcement of twin girders spanning First Street are complete at the beleaguered Salesforce Transit Center in San Francisco. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Round-Up (06/29/22)

July 11, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
Housing market activity is on the downtick, the Partnership for Global Infrastructure and Investment launches, the SEC proposes a climate rule that signals a new era for real estate, and more.

The U.S. and other members of the G-7 including Canada, Germany, and Japan launched the Partnership for Global Infrastructure and Investment, which aims to raise $600 billion for global infrastructure projects. (Su-Lin Tan, CNBC)
Housing market activity decreases rapidly, with mortgage rates spiking to the highest levels since 2009. (Andrea Riquier, Forbes Advisor)
Industrial real estate developers increase the amount of cold-storage warehouses being built in the U.S., betting on pandemic-driven changes in the way consumers buy groceries and meals are here to stay. (Liz Young, The Wall Street Journal)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Construction Litigation Roundup: “You Have No Class(ification)”

May 13, 2024 — Daniel Lund III - Lexology
In fact, you didn’t even have a license. A federal court in Alabama was tasked with determining whether an unlicensed contractor could recover from an Alabama project owner for in excess of $1.7 million in construction infrastructure and site work performed. In fact, the contractor “did not have a valid general contractor’s license” in the state of Alabama when it “assumed work on the project from its predecessor company.” During the course of work on the project, the principals of an original contractor decided to go their separate ways, whereupon one of those principals announced that his new company would take over ongoing work. Roughly two months after the new company began working at the project, the contractor applied for a license with the Alabama Licensing Board of General Contractors – the license was issued within about 45 days. Then, some eight months later, the contractor added a “municipal and utilities” classification to its contractor license. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

As Trump Visits Border, Texas Landowners Prepare to Fight the Wall

February 11, 2019 — Associated Press - Engineering News-Record
HIDALGO, Texas (AP) — As President Donald Trump traveled to the border in Texas to make the case for his $5.7 billion wall , landowner Eloisa Cavazos says she knows firsthand how the project will play out if the White House gets its way. The federal government has started surveying land along the border in Texas and announced plans to start construction next month. Rather than surrender their land, some property owners are digging in, vowing to reject buyout offers and preparing to fight the administration in court. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES