Cambridge Massachusetts Building Expert Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

First Look at Long List of AEC Firms Receiving PPP Loans

July 20, 2020 — Tom Ichniowski & Scott Blair - Engineering News-Record
Thousands of construction and design firm from all parts of the U.S. appear on lists of companies that have received federal Paycheck Protection Program forgivable loans, according to federal documents just made public. Reprinted courtesy of Tom Ichniowski, Engineering News-Record and Scott Blair, Engineering News-Record Mr. Ichniowski may be contacted at ichniowskit@enr.com Mr. Blair may be contacted at blairs@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

California Court of Appeal Clarifies Intent of Faulty Workmanship Exclusions

October 26, 2017 — Tiffany Casanova – Saxe Doernberger & Vita, P.C.
Last month, in Global Modular, Inc. v. Kadena Pacific, Inc., 1 a California Court of Appeal clarified the meaning of the frequently asserted j.(5) and j.(6) exclusions of the standard commercial general liability policy; an issue the court deemed one of “first impression” for the state. The court took a close look at how courts nationwide handle the exclusions and relied on the policy language to come to a policyholder-friendly decision. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Casanova, Saxe Doernberger & Vita, P.C.
Ms. Casanova may be contacted at tlc@sdvlaw.com

Bank Sues over Defective Windows

July 31, 2013 — CDJ STAFF
The Federal Reserve Bank of St. Louis replaced 498 windows in its building in 2008. According to a consultant, they all have to be replaced again. The bank estimates that the damages will exceed $1.5 million, and they are suing the contractor who installed them, the window manufacturer, and others. The windows were replaced to provide greater blast protection. But in 2011, the bank found that the special glass used was beginning to delaminate. The Federal Reserve is seeking to have all of the windows replaced “with windows that meet the specifications of the contract.” McCarthy Building Construction says that it is attempting to resolve things. The contractor noted that it is “continuing to work with the Federal Reserve and other parties and hope we can resolve this matter in a timely manner.” Read the court decision
Read the full story...
Reprinted courtesy of

Texas Court Requires Insurer to Defend GC Despite Breach of Contract Exclusion

December 19, 2018 — Ashley L. Cooper - Saxe Doernberger & Vita, P.C.
In Mt. Hawley Insurance Co. v. Slay Engineering, et al.,1 a Texas federal court ruled in favor of a general contractor, finding that its insurer had a duty to defend it in a construction defect case filed by the owner. The decision adds more clarity to the interpretation of the subcontractor exception to the “Damage to Your Work” exclusion as well as the Breach of Contract exclusion, which has been the subject of several cases coming out of Texas over the past decade. Read the court decision
Read the full story...
Reprinted courtesy of Ashley L. Cooper, Saxe Doernberger & Vita, P.C.
Ms. Cooper may be contacted at alc@sdvlaw.com

Nevada State Senator Says HOA Scandal Shows Need for Construction Defect Reform

November 13, 2013 — CDJ STAFF
A Nevada State Senator sees the ongoing HOA scandal as a sign that the state’s construction defect laws need to be revised. State Senator Mike Schneider says that the law “is flawed and actually makes it too easy to do what these folks have done.” What these folks have done has, of course, lead to a number of indictments and guilty pleas in federal court. One problem that Senator Schneider points to in current Nevada construction defect law is that homeowner attorneys get 40% of any settlement, sometimes leaving homeowners without sufficient funds to repair the defects. “It’s gotten out of hand. We pay some outrageous costs and fees in this cases.” Read the court decision
Read the full story...
Reprinted courtesy of

Occurrence Found, Business Risk Exclusions Do Not Bar Coverage for Construction Defects

May 13, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that the supplier of cement for the construction of pools had coverage for alleged construction defects in the finished pools. Harleysville Worcester Ins. Co. v. Paramount Concrete, Inc., 2014 U.S. Dist. LEXIS 43889 (D. Conn. March 31, 2014). R.I. Pools sued Paramount, a manufacturer and supplier of shotcrete, after cracking appeared in nineteen pools built by R.I. Pools using Paramount's shotcrete. The jury awarded R.I. Pools compensatory damages of $2,760,000. Paramount's insurer, Harleysville, defended under a reservation of rights. After the verdict, Harleysville filed for a declaratory judgment that there was no coverage under the CGL policy. Paramount filed for partial summary judgment. Harleysville first argued there was no occurrence. The policy's definition of occurrence included the phrase, "continuous exposure." This broadened the term "occurrence" beyond the word accident to include a situation where damage occurred over a period of time, rather than suddenly or instantaneously. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurers Dispute Sharing of Defense in Construction Defect Case

May 13, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The California Court of Appeal affirmed the trial court's decision that the defending insurer was not entitled to reimbursement of defense costs from another insurer based upon a subcontract and additional insured endorsement. Zurich Am. Ins. Co. v. Old Republic Gen. Ins. Corp., 2024 Cal. App. Unpub. LEXIS 1261 (Cal. Ct. App. Feb. 28, 2024). Martin McNerney Development Company (McNerney) entered a construction contract to perform seismic upgrades and tenant improvements for condominiums. McNerney and Broadway Mechanical Contractors, Inc. (Broadway) entered a "Subcontract Agreement" under which Broadway was to perform plumbing work at the project. The agreement required Broadway to maintain general liability insurance naming McNerney as an additional insured for work performed on the project, including completed operations. The subcontract also required Broadway to indemnify and hold McNerney harmless with respect to all claims for damage to property arising out of work performed by Broadway. Broadway completed its work on the project in September 2007. Broadway issued a one-year warranty for its work on the project. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES