Seattle Washington Building Expert Directory

Recent Amendments and Caselaw Affecting the Construction Industry in Texas

April 19, 2022 — Frederick H. Wen - Gordon Rees Scully Mansukhani, LLP
Here are some recent Texas legislative amendments and Texas Supreme Court cases from the past year concerning the construction industry in Texas. 1) Recent Legislative Amendments Concerning the Construction Industry: a) The Texas Legislature throws a “Spear” in the Lonergan Doctrine to reduce general/subcontractor liability for owner-provided plans and specs: Forty-nine out of the fifty states follow the Spearin Doctrine under which owners warrant the accuracy and sufficiency of owner-provided plans and specs in construction contracts. On the other hand, for over a century, Texas has followed the Lonergan Doctrine under which, absent contractual language to the contrary, a general contractor/subcontractor, instead of the owner, bears the risk of deficiencies in owner-provided design documents, once they started construction. Texas Senate Bill 219, which went into effect on September 1, 2021, finally changed that and brought Texas in line with the rest of the country, with a few exceptions. Read the court decision
Read the full story...
Reprinted courtesy of Frederick H. Wen, Gordon Rees Scully Mansukhani, LLP
Mr. Wen may be contacted at fhwen@grsm.com

Can I Record a Lis Pendens in Arizona if the Lawsuit is filed Another Jurisdiction?

September 26, 2022 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
Recent research I did on a case led me to the conclusion that Arizona law recognizes foreign litigation (i.e., a lawsuit filed outside of Arizona) as a justification for the recording of a lis pendens against real property located within Arizona. See TWE Retirement Fund Trust v. Ream, 198 Ariz. 268 (Ct. App. 2000). Apparently, there’s some debate about whether foreign litigation can support a local lis pendens. See Boca Petroco, Inc. v. Petroleum Realty II, 285 Ga. 487 (Ga. 2009). As noted in the TWE case, Arizona’s lis pendens statute (A.R.S. 12-1191) does not discriminate between local or foreign “actions.” As such, if litigation is pending anywhere that affects Arizona real property, a lis pendens can (and probably should) be filed. Reprinted courtesy of Ben Reeves, Snell & Wilmer Mr. Reeves may be contacted at breeves@swlaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Crisis Averted! Pennsylvania Supreme Court Joins Other Courts in Finding that Covid-19 Presents No Physical Loss or Damage for Businesses

October 21, 2024 — Edward M. Koch & Marc L. Penchansky - White and Williams LLP
Seeking to find some relief from business losses experienced during the COVID-19 pandemic, many businesses turned to their property insurers for coverage for their lost income. A clear national trend emerged among courts deciding the issue, as most businesses could not establish coverage because they had not experienced a “direct physical loss of or damage to their covered property” as required by most policies. While this legal question may have become an afterthought for many attorneys, the question remained an open one in Pennsylvania while the Pennsylvania Supreme Court considered two contradictory holdings issued in the Superior Court on this topic. Compare Macmiles, LLC v. Erie Ins. Exch., 286 A.3d 331 (Pa. Super. 2022) (holding there was no coverage for loss of use of a commercial property unaccompanied by any physical alteration or other physical condition that rendered the property unusable or uninhabitable) with Ungarean v. CNA, 286 A.3d 353 (Pa. Super. 2022) (holding that the policy at issue was ambiguous and therefore the policy covered the insured for COVID-related business losses). Last week, the Supreme Court considered the Superior Court’s holdings in Macmiles and Ungarean and held, at long last, that COVID-19 did not cause a direct physical loss of or damage to covered property. Reprinted courtesy of Edward M. Koch, White and Williams LLP and Marc L. Penchansky, White and Williams LLP Mr. Koch may be contacted at koche@whiteandwilliams.com Mr. Penchansky may be contacted at penchanskym@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

New York Labor Laws and Action Over Exclusions

February 01, 2021 — Theresa A. Guertin & Ashley McWilliams - Saxe Doernberger & Vita, P.C.
One of the most important methods for shifting risk in the construction context is insurance coverage. Upstream parties such as owner/developers and general contractors typically require that their downstream subcontractors who perform work on their properties or projects bring specific insurance to the table. These insurance requirements have a twofold purpose: protect the upstream parties, through additional insured coverage, from liabilities caused by the subcontractor; and protect the downstream parties by ensuring that they have adequate insurance for their own potential liabilities. In New York, subcontractor insurance coverage can have some surprising terms which frustrate risk transfer. Numerous policies contain “Action Over” exclusions, which bar coverage for one of the most significant exposures faced by owner-developers and general contractors: bodily injury lawsuits brought by subcontractor employees. It is critical that upstream parties understand the unique impact of New York’s labor laws on the insurance market and be prepared to identify and request removal of Action Over exclusions on subcontractor insurance policies. Reprinted courtesy of Theresa A. Guertin, Saxe Doernberger & Vita, P.C. and Ashley McWilliams, Saxe Doernberger & Vita, P.C. Ms. Guertin may be contacted at TGuertin@sdvlaw.com Ms. McWilliams may be contacted at AMcWilliams@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

New California Employment Laws Affect the Construction Industry for 2019

February 18, 2019 — Smith Currie
The California Legislature introduced more than 2637 bills in the second half of the 2017-2018 session that became law effective January 1, 2019, many of which address employment issues facing California employers in the construction industry. Below we have summarized some of the more important laws (the summary titles are live links to the text of the new law), and employers are urged to protect their companies by updating contracts, policies, and/or practices for compliance. The following is for general knowledge, and we recommend you consult with your attorney for specific legal advice. AB 1565 – Contractor Wage Liability: AB 1565 repeals the provision that relieved direct contractors for liability for anything other than unpaid wages and fringe or other benefit payments or contributions, including interest owed. In the past, a direct contractor could withhold “disputed” sums owed to a subcontractor if the subcontractor failed to provide “information” about their and lower-tier subcontractors’ payroll records. Read the court decision
Read the full story...
Reprinted courtesy of Smith Currie
Smith Currie attorneys may be contacted at info@smithcurrie.com

You’re Only as Good as Those with Whom You Contract

April 17, 2019 — Christopher G. Hill - Construction Law Musings
I have been beating the drum of the need to have a solid construction contract as the basis for your construction project and contractor/subcontractor/supplier relationships. I have also emphasized that communication early and often is one of the best ways to assure a smooth project. However, the sad truth is that even with the best contract drafted with the assistance of an experienced construction attorney, if the other party to the contract simply decides not to perform, whether that is through unjustified non-payment or simple refusal to complete a scope of work without reason, it will be an expensive proposition to force compliance or be compensated for the monetary damage caused by such actions. It is this often unmentioned truth relating to any contract, including those that construction professionals in Virginia deal with on a daily basis, that makes having a good knowledge of those with whom you plan to contract is key to a successful (read profitable) construction project. Of course be sure that any contractor or subcontractor you contract with has the basics of propoer insurance, the right experience and of course a contractor’s license with the proper specialty or specialties. These basics will get you most of the way to assuring that those that contract with you at least are responsible in business. Another key component, if you can find this information out, is the financial wherwithall of the other party. For a General Contractor, this means both sides of the equation: Owner and Subcontractors. For a Subcontractor, the key is the Contractor, but any other information you can get on the Owner is helpful (though this can be difficult) particularly in the face of a “pay if paid” clause. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

ENR Northwest’s Top Contractors Survey Reveals Regional Uptick

June 25, 2019 — Scott Judy - Engineering News-Record
A year ago, the 25 contractors responding to ENR Northwest’s Top Contractors survey collectively reported roughly $6.4 billion in 2017 revenue from the states of Washington, Oregon and Alaska. This year, the 27 contractors listed below—in alphabetical order—reported more than $8.8 billion in regional revenue for 2018. Read the court decision
Read the full story...
Reprinted courtesy of Scott Judy, ENR
Mr. Judy may be contacted at judys@enr.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES