Fairfield Connecticut Building Expert Directory

Are You Ready For 2015?

January 07, 2015 — Craig Martin- Construction Contractor Advisor Blog
Last month’s Engineering News Record Magazine contained an editorial noting the worst projects of the year. Are you prepared if you have a bad project? As the editors aptly pointed out: "By their nature, bad projects disappoint owners, incite hostility among team members, slip months and years past scheduled completions and drain finances." ENR pointed noted a few projects from 2014 that did not go well. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Changing Course Midstream Did Not Work in River Dredging Project

December 10, 2015 — Craig Martin – Construction Contractor Advisor
A contractor learned a $12M lesson when it tried to change course on a Corps of Engineer river dredging project. The case also illustrates the importance of documenting problems on a project and providing notice of those problems to the owner. In Weston/Bean Joint Venture v U.S., Weston/Bean was awarded a Corps of Engineers project to provide maintenance dredging on the Miami River to a depth of 15 feet. The contract noted that the contractor may experience sediment, debris and rock, including soft to moderately hard limestone. The contractor encountered rocks early on in the project, but consistently submitted reports to the Corps of Engineers that nothing was experienced on the project that would lead to a change order or claim. And, for the first year of operations, the contractor made no claim for differing site conditions. Instead, the contractor terminated the subcontractor for not being able to process the rock uncovered during the dredging process. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Third Circuit Vacates Judgment for Insurer on Alleged Construction Defect Claim

December 31, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Third Circuit vacated and remanded to the district court the judgment in favor of the insurer on a construction defect claim. Odedeyi v. AmTrust Financial Services Inc., 2024 U.S. App. LEXIS 24729 (3d Cir. Oct. 1, 2024). Mr. Odedeyi hired a contractor, who was insured by Security National, to perform work on his property. After the property was damaged during the renovations, Odedeyi filed suit against the contractor. Odedeyi was awarded a default judgment against the contractor. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Difficult Task for Court to Analyze Delay and Disorder on Construction Project

August 23, 2021 — David Adelstein - Florida Construction Legal Updates
One of my favorites quotes from a case, and I am sure others in the construction industry feel the same way or can relate, is from the District of Columbia Court of Appeals in Blake Construction Co., Inc. v. C.J. Coakley Co., Inc., 431 A.2d 569, 575 (D.C. 1981):

We note parenthetically and at the outset that, except in the middle of a battlefield, nowhere must men coordinate the movement of other men and all materials in the midst of such chaos and with such limited certainty of present facts and future occurrences as in a huge construction project such as the building of this 100 million dollar hospital. Even the most painstaking planning frequently turns out to be mere conjecture and accommodation to changes must necessarily be of the rough, quick and ad hoc sort, analogous to ever-changing commands on the battlefield. Further, it is a difficult task for a court to be able to examine testimony and evidence in the quiet of a courtroom several years later concerning such confusion and then extract from them a determination of precisely when the disorder and constant readjustment, which is to be expected by any subcontractor on a job site, become so extreme, so debilitating and so unreasonable as to constitute a breach of contract between a contractor and a subcontractor.

Do you agree with this sentiment? The reality is that retrospectively analyzing delay on a complicated construction project with numerous moving parts on a day-by-day, hour-by-hour, basis is no easy feat. It is not easy for the parties and certainly not easy for courts to unravel. With every party claiming delay based on a retrospective analysis there will be another party with either a different delay analysis or providing credible cross examination as to flaws with the delay analysis. The same bodes true with loss of productivity / inefficiency claims and the particular case-specific facts are important, preferably with evidence such as photos, videos, notifications, daily reports, manpower reports, etc., supporting the facts. But the facts are complicated, and the delay analysis is complicated, and it is a difficult task for a trier of fact to unravel these facts. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Taking Advantage of New Tax Credits and Prevailing Wage Bonuses Under the Inflation Reduction Act for Clean Energy Construction Projects

September 02, 2024 — Abby Bello Salinas, Jennifer Harris & Sahara Mokhtari - ConsensusDocs
Introduction: IRA Boosts U.S. Construction Industry On August 16, 2022, President Biden signed the Inflation Reduction Act of 2022 (the “IRA”) into law.[1] The IRA marked a legislative milestone for clean energy in the United States in part by providing funding mechanisms for clean energy infrastructure projects. This new emphasis on green projects has already created a surge of opportunities across the construction industry—the Internal Revenue Service (“IRS”) estimates that IRA clean energy projects will create over 1.5 million jobs over the next decade.[2] But what can contractors do to take advantage of IRA incentives to reduce costs, build a reliable workforce, and gain a competitive advantage in the new infrastructure landscape created by the ever-increasing number of IRA-related projects? The IRS Final Rule, 89 FR 53184 (29 CFR 1), effective August 26, 2024, provides some guidance by outlining the increased credits and deductions available to taxpayers that satisfy the criteria under the IRA, such as prevailing wage and registered apprenticeship requirements. Reprinted courtesy of Abby Bello Salinas, Peckar & Abramson, P.C., Jennifer Harris, Peckar & Abramson, P.C. and Sahara Mokhtari, Georgetown Law Class of 2025 Ms. Salinas may be contacted at asalinas@pecklaw.com Ms. Harris may be contacted at jharris@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Luxury Villa Fraudsters Jailed for Madeira Potato Field Scam

September 25, 2018 — Franz Wild - Bloomberg
Four men and a woman convicted of conning people to invest in a fraudulent luxury villa construction scheme on a potato field in the Portuguese island of Madeira were sentenced to as long as 5 1/2 years in a U.K. jail. Read the court decision
Read the full story...
Reprinted courtesy of Franz Wild, Bloomberg

Sometimes You Get Away with Default (but don’t count on it)

July 27, 2020 — Christopher G. Hill - Construction Law Musings
As an almost universal rule here in Virginia, failing to show up for court or respond to a lawsuit is a bad idea. Consequences include default judgment against you without the right to defend or make your case. Courts simply enter judgment and the consequences of that judgment will follow. However, and as is often the case around here, there are small exceptions where the courts of Virginia allow the defaulting party off the hook. Sullivan Mechanical Contractors, Inc. v. KBE Building Corporation is just such a case. In Sullivan Mechanical, the Federal District Court for the Western District of Virginia was faced with a Motion to Vacate Default Judgment from KBE. The facts are laid out in the opinion, but basically come down to the usual subcontractor not paid by the general contractor and general contractor has reasons for non-payment. Subcontractor, Sullivan Mechanical, sued KBE and KBE failed to respond in a timely manner. One day after the deadline for response had passed, Sullivan moved for entry of default and the clerk entered the default that same day. KBE moved to vacate the default a mere 6 days after entry of default. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Canada Cooler Housing Market Boosts Poloz’s Soft Landing

April 15, 2014 — Greg Quinn – Bloomberg
Declines in housing starts and building permits data suggest Canada is headed for the soft landing in real estate that policy makers have forecast, damping concern that a rapid fall in home prices could hobble the world’s 11th-largest economy. Home construction dropped 18 percent in March to the lowest annual pace since the 2009 recession, Canada Mortgage & Housing Corp. said from Ottawa today. Residential building permits also dropped 21 percent in February from January’s record high, Statistics Canada said in a separate report. Bank of Canada Governor Stephen Poloz has said the housing market is heading for a “soft landing” with consumer debts as a share of income stabilizing around record highs. The International Monetary Fund said today that house prices and household finances remain a “key vulnerability” for Canada. Read the court decision
Read the full story...
Reprinted courtesy of Greg Quinn, Bloomberg
Mr. Quinn may be contacted at gquinn1@bloomberg.net

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES