Seattle Washington Building Expert Directory

Contractual Assumption of Liability Does Not Bar Coverage

August 27, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Michigan Court of Appeals rejected the insurer's argument that coverage was barred for the insured's contractual assumption of liability of another. Travelers Prop. Cas. Co. of Am v. Peaker Serv., Inc., 2014 WL 3605680 (Mich. Ct. App. July 22, 2014). The contractor was hired to install an "electronic over-speed system" at the University of Michigan. The hope was that the new system would prevent the steam turbines at the central power plant from turning too quickly. The parties' contract provided, “Section 15.18. Supplier Damage to University Property. Without regard to any other section of the Agreement, Supplier shall be responsible for the costs to return to ‘as was’ condition from any damage caused to the building, grounds, or other equipment and furnishings caused in whole or part by Supplier Personnel while performing activities arising under this Agreement.” The contractor improperly calibrated the system, causing one of the university's turbines to operate at twice the safe operational speed, causing significant damage to the generator equipment. The university sued the contractor for more than $3 million in damages. Travelers defended, but filed a declaratory judgment action, contending that coverage did not exist because the "contractual liability" exclusion applied. Section 15.18 of the contract purportedly constituted an "assumption" of the insured's own liability, and was therefore not covered under the CGL policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

U.S. Judge Says Wal-Mart Must Face Mexican-Bribe Claims

October 01, 2014 — Jef Feeley – Bloomberg
Wal-Mart Stores Inc. (WMT) was ordered by a federal judge in Arkansas to face a pension fund’s claims the retailer defrauded shareholders by concealing corruption tied to bribes allegedly paid by officials of its Mexican unit. U.S. District Judge Susan Hickey in Fayetteville rejected Wal-Mart’s bid to throw out the Michigan-based fund’s lawsuit accusing it of making misleading statements to regulators about claims it paid bribes to facilitate Mexican real-estate deals. The world’s largest retailer has said it’s spent $439 million since 2012 in connection with investigations into allegations that employees paid bribes in Mexico, China, India and Brazil. Both U.S. and Mexican prosecutors have said they are probing whether executives of Wal-Mart’s Mexican unit were paying off local officials to clear the way for construction of new stores and warehouses. Read the court decision
Read the full story...
Reprinted courtesy of Jef Feeley, Bloomberg
Mr. Feeley may be contacted at jfeeley@bloomberg.net

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Gordon & Rees Ranks #5 in Top 50 Construction Law Firms in the Nation

June 29, 2020 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani has been ranked the #5 construction law firm in the nation by Construction Executive in the magazine’s 2020 ranking of The Top 50 Construction Law Firms. Gordon & Rees is the only California-based law firm to rank in the Top 25. The firm was ranked in the Top 10 in more specific areas as well.

#1 in the Top 10 Law Firms Ranked by Most Locations
#2 in the Top 10 Law Firms Ranked by Number of Construction Attorneys
#6 in the Top 10 Law Firms Ranked by Number of States Admitted to Practice

“With offices throughout the nation and outstanding construction attorneys in many of those offices, we are able to offer our construction clients a diverse range of legal services wherever they do business,” said Ernie Isola partner and co-chair of the firm’s construction practice group. Read the court decision
Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

No Coverage for Tenant's Breach of Contract Claims

April 05, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The court granted summary judgment to the insurer, finding there was no duty to defend or indemnify a tenant/insured's contract-related claims. Erie Ins. Exch. v. Little Ducklings Daycare Associates, LP, 2017 Phila. Ct. Com. Pl. LEXIS 22 (Pa. D. Jan. 25, 2017). Little Ducklings Daycare Preschool ("tenant") leased from the Estate of Carmen Neri ("landlord") premises to run a day care center for five years. The lease identified two of tenant's members, Maryanne L. Hatzold and Thomas Hatzold, as guarantors for the lease. The Hatzolds ("Guarantors") delivered to the landlord a written lease guaranty agreement. The guarantee assured the full payment and satisfaction of the rent owed under the lease. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

CDJ’s #4 Topic of the Year: KB Home Greater Los Angeles, Inc. v. The Superior Court of Los Angeles County

December 31, 2014 — Beverley BevenFlorez-CDJ STAFF
KB Home, another case that clarified California’s SB 800, was analyzed by Amy Kuo Alexander of Gordon & Rees LLP in her article on “New Developments Related to SB 800.” Read the full story... KB Home was also discussed by Cvitanovic and Stefco of Haight Brown & Bonesteel in their article on Burch. Read the court decision
Read the full story...
Reprinted courtesy of

Design Professional Asserting Copyright Infringement And Contributory Copyright Infringement

May 01, 2019 — David Adelstein - Florida Construction Legal Updates
Standard form construction contracts between an owner and design profesional will address copyright protection, as well as other contractual protections, associated with a design professional’s “instruments of service.” An owner negotiating an agreement with a design professional should consider alternative language that broadens the scope of the contractual license given to it with respect to the use of the design. Regardless, a design professional’s copyright infringement claim is still a challenging claim to ultimately prevail on. While a design professional may likely survive the motion to dismiss stage in a copyright infringement claim, whether it survives the summary judgment stage is another, more challenging, story. “To state a claim for copyright infringement a plaintiff [design professional] must assert [and prove the following two prongs]: ‘(1) ownership of a valid copyright, and (2) copying of constituent elements of the work that are original.’” Robert Swedroe Architect Planners, A.I.A., P.A. v. J. Milton & Associates, Inc., 2019 WL 1059836, *3 (S.D.Fla. 2019) quoting Feist Publ’ns, Inc. v. Rural Tel. Serv. Co., Inc., 499 U.S. 340, 361 (1991). In the first prong, the design professional must establish it complied with statutory formalities to own a valid copyright. Id. In the second prong, the design professional must establish that the defendant copied constituent elements that are original. Id. There is also a claim known as contributory copyright infringement. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dadelstein@gmail.com

Insurer's Summary Judgment Motion to Reject Claim for Construction Defects Upheld

August 15, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The Third Circuit upheld the district court's order granting summary judgment in favor of the insurer on a claim seeking coverage for construction defects. Lenick Constr. v. Selective Way Ins. Co., 2018 U.S. App. LEXIS 15197 (3d Cir. June 6, 2018). Westrum was the general contractor for a 92 unit development, and it subcontracted with Lenick to perform rough and finish carpentry and to install paneling, windows, and doors provided by the developer. After the project was completed, it was discovered that some units experienced water infiltration, leaks and cracked drywall. The condominium development sued Westrum, alleging contract and warranty claims. Westrum impleaded Lenick, asserting claims for breach of contract and indemnification. Lenick sought a defense from its insurer, Selective. Selective defended under a reservation of rights. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES