California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 —
CDJ STAFFThe California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Lost Productivity or Inefficiency Claim Can Be Challenging to Prove
May 02, 2022 —
David Adelstein - Florida Construction Legal UpdatesOne of the most challenging claims to prove is a lost productivity or inefficiency claim. There is an alluring appeal to these claims because there are oftentimes intriguing facts and high damages. But the allure of the presentation of the claim does not compensate for the actual burden of proof in proving the lost productivity or inefficiency claim, which will require an expert. And they really are challenging to prove.
Don’t take it from me. A recent Federal Claims Court opinion, Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, (Fed.Cl. 2022), that I also discussed in the preceding
article, exemplifies this point.
To determine lost productivity or inefficiency, the claimant’s expert tried three different methodologies.
First, the expert looked at industry standard lost productivity factors such as those promulgated by the Mechanical Contractor’s Association. However, the claimant was not a mechanical contractor and there is a bunch of subjectivity involved when using these factors. The expert decided not to use such industry standard factors correctly noting they provide value when you are looking at a potential impact prospectively, but once you incur actual damages and have real data, it is not an accurate measure.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Florida Former Public Works Director Fined for Ethics Violation
April 09, 2014 —
Beverley BevenFlorez-CDJ STAFFHiram Siaba, formerly Miami Lake, Florida’s public works director, has been fined for allegedly violating “an ethics ordinance that prevents public employees from doing business with former employers for a two-year period,” according to the Miami Herald. A few months prior to taking the job with the city, Siaba had worked part-time for Ballarena Construction. Siaba awarded Ballarena Construction “more than 10 projects that fell below the $25,000 threshold for awarding contracts without going to the Town Council for approval.”
Ballarena had also been awarded a million-dollar youth center project, which “came to a halt last year” when town officials alleged that structural defects were discovered during an inspection. Miami Lakes is currently negotiating with Ballarena’s surety company to attempt to finish the project.
Read the court decisionRead the full story...Reprinted courtesy of
Town Sues over Defective Work on Sewer Lines
January 13, 2014 —
CDJ STAFFThe Handy Sanitary District in North Carolina has filed a lawsuit against one of the subcontractors on the Badin Lake Sewer Project, which the Lexington Dispatch describes as “delay riddled.” The town claims that the materials used by Hobbs, Upchurch and Associates “were not adequate for the project.” Additionally, the town claims that valves were improperly installed or damaged, and that pipes were of the incorrect type and improperly connected.
The Sanitary District Board of Commissioners has additionally settled a lawsuit over non-payment for work on the sewer project. The Handy Sanitary District has settled claims brought by Monroe Roadways Contractors and Young Construction with a payment of $250,000.
Read the court decisionRead the full story...Reprinted courtesy of
Delays in Filing Lead to Dismissal in Moisture Intrusion Lawsuit
September 09, 2011 —
CDJ STAFFThe Alabama Court of Civil Appeals has upheld a summary judgment in the case of Franklin v. Mitchell. Walter Mitchell, doing business as Southern Classic Construction built a new home for the Franklins. The Franklins moved into the home in October 2001. In April 2006 they discovered sagging floors in both the bathroom and kitchen. They contacted Mitchell who suggested the flooring might be defective. The Franklins spent eight months attempting to contact the flooring manufacturer.
In March 2007, the Franklins had the home inspected. The sagging was determined to be due to a loss of strength in the decking because of condensation from the air conditioning system. Air returns were not properly sealed and drawing moisture into the structure. There was mold on the decking and floor joints.
When Mitchell was contacted by the Franklins, he told them his one-year warranty had expired but had the HVAC subcontractor, Southern Mechanical Heating & Air (owned by Mitchell’s father, Jim Mitchell), look at the situation. SMHA replaced and braced subfloors. Later, they entered the crawl space to tape ducts, seal the air return, and insulate the air vent housing. The Franklins were not satisfied with the repairs, as not all the ducts were taped, nor were the air vent housings insulated.
Franklin complained to Walter Mitchell who again cited his one-year warranty. Jim Mitchell said he would not report complaints to his insurer, stating that the repairs were unnecessary, that the work had been done correctly in the first place, and it was only done at the request of Walter Mitchell.
In February 2009, the Franklins sued Walker Mitchell. Mitchell denied the claims, citing in part the statute of limitations. Mitchell also filed complaints against three subcontractors, including his father’s firm. Mitchell received a summary judgment as the case started after Alabama’s six-year statute of limitations.
The appeals court rejected the Franklin’s argument that the claim of damage did not start until they were aware it was due to a construction defect. The court noted that as Walter Mitchell was licensed as a “residential home builder, the statute the Franklins cite did not apply, as it concerns architects, engineers, and licensed general contactors.”
Nor did they feel that Mitchells’ claim that his warranty had expired were sufficient to override the statute of limitations, quoting an earlier case, “Vague assurances do not amount to an affirmative inducement to delay filing suit.” Their claim of subsequent negligent repairs was rejected because Mitchell did not direct the specific actions taken by his father’s firm.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Appraiser Declarations Inadmissible When Offered to Challenge the Merits of an Appraisal Award
March 14, 2018 —
Valerie Moore and Christopher Kendrick - Publications & InsightsIn
Khorsand v. Liberty Mutual Fire Ins. Co. (No. B280273, filed 2/27/18), a California appeals court affirmed an appraisal award favorable to a homeowners insurer, ruling that it was improper to admit as evidence in opposition to a petition to confirm the award a declaration from the policyholders’ appraiser, except for the limited purpose of showing improprieties in the appraisal, bias, partiality or other improper conduct.
The homeowners had a pipe leak and submitted a claim. The insurer responded to an estimate from the owners’ adjuster by retaining an expert and paying an undisputed amount that was significantly less. Eleven months later the owners had upper deck damage and submitted another claim. Relying on the same expert, the insurer paid another undisputed amount significantly less than the owner’s estimate. The owners requested appraisal but the insurer denied the request, contending that the dispute was over coverage and outside the scope of appraisal.
The owners’ petition for appraisal was granted, with the court ordering separate listing of items the insurer disputed regarding coverage or causation. The appraisal panel issued an award stating that total damage was $132,293, of which $96,530 was contested by the insurer. The insurer filed a petition to confirm the award, which was granted despite the fact that the owners’ appraiser had refused to sign it.
Reprinted courtesy of
Valerie Moore, Haight Brown & Bonesteel LLP and
Christopher Kendrick, Haight Brown & Bonesteel LLP
Ms. Moore may be contacted at vmoore@hbblaw.com
Mr. Kendrick may be contacted at ckendrick@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Fannie-Freddie Propose Liquidity Rules for Mortgage Insurers
July 16, 2014 —
Clea Benson and Zachary Tracer – BloombergMs. Benson may be contacted at cbenson20@bloomberg.net; Mr. Tracer may be contacted at ztracer1@bloomberg.net
Private mortgage insurers looking to do business with Fannie Mae and Freddie Mac would have to hold minimum amounts of liquid assets under standards proposed by the companies and their regulator.
To back loans packaged into securities by the U.S.-owned mortgage-finance giants, insurers would have to hold liquid assets worth at least 5.6 percent of their risk exposure, and possibly more depending on the quality of the loans they cover, according to the proposal released today by the companies and the Federal Housing Finance Agency.
“Mortgage insurance counterparties must be able to fulfill their intended role of providing private capital, even in adverse market conditions,” FHFA Director Melvin L. Watt said in an e-mailed statement.
Ms. Benson may be contacted at cbenson20@bloomberg.net; Mr. Tracer may be contacted at ztracer1@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Clea Benson and Zachary Tracer, Bloomberg
Federal Magistrate Judge Recommends Rescission of Policies
February 12, 2024 —
Craig Rokuson - Traub LiebermanIn the recent case of Union Mut. Fire Ins. Co. v. 142 Driggs LLC, 2023 U.S. Dist. LEXIS 220393, Magistrate Judge Lois Bloom of the United States District Court for the Eastern District of New York recommended granting the insurer's default judgment and holding that of three policies issued to 142 Driggs LLC ("Driggs") be rescinded ab initio.
Driggs had represented on its insurance applications that it did not provide parking to anyone other than itself, tenants, and its guests at the subject insured premises. However, Union Mutual learned that Driggs had been renting out three garages to non-tenants. Second, Driggs represented that the mercantile square footage was around 1,000 square feet, when in actuality, it was larger than allowed under the policies.
Union Mutual provided underwriting guidelines in connection with its default motion, which state that "parking provided for anyone other than the insured, tenants and their guests," presents an "unacceptable risk." The guidelines also state that answering yes to any "preliminary application questions (which presumably included those regarding mercantile square footage and parking) is an "unacceptable risk." The court held that these guidelines supported a finding that Driggs made material misrepresentation and that Union Mutual relied on these misrepresentations in issuing the policies. The court, as such, recommended that the policies at issue be rescinded from inception.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Rokuson, Traub LiebermanMr. Rokuson may be contacted at
crokuson@tlsslaw.com
