Seattle Washington Building Expert Directory

Specification Challenge; Excusable Delay; Type I Differing Site Condition; Superior Knowledge

January 02, 2024 — David Adelstein - Florida Construction Legal Updates
An Armed Services Board of Contract Appeals dispute, Appeal of L.S. Black-Loeffel Civil Constructors JV, ASBCA No. 62402, 2023 WL 5827241 (ASBCA 2023), involved which party bore liability for delay—the federal government or the prime contractor–based on various legal theories. Without detailing the factual details, a number of interesting legal issues were raised in this dispute including (1) a defective specification challenge, (2) excusable delay, (3) Type I differing site condition, and (4) superior knowledge. These legal issues are discussed below. 1. Specification Challenge (Defective Specifications) The contractor claimed that the government’s specifications were defective in regard to a thermal control plan. The government countered that the specifications were not design specifications but performance specifications. The specifications were performance based because they did not tell the contractor how to achieve the performance-based criteria. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Three Attorneys Named Among The Best Lawyers in America 2018

August 24, 2017 — Haight Brown & Bonesteel LLP
Partners Denis Moriarty and Mark VonderHaar, and Of Counsel William Baumgaertner were selected by their peers for inclusion in The Best Lawyers in America 2018. This marks the twelfth consecutive year Mr. Baumgaertner has been listed for his defendants’ and plaintiffs’ work in personal injury and product liability litigation, and the sixth consecutive year Mr. Moriarty has been listed for his work in insurance law. Mr. VonderHaar was listed for the first time for his work in insurance law. Read the court decision
Read the full story...
Reprinted courtesy of

Citigroup Reaches $1.13 Billion Pact Over Mortgage Bonds

April 09, 2014 — Dakin Campbell – Bloomberg
Citigroup Inc. (C) agreed to pay $1.13 billion to settle claims from mortgage-bond investors as it seeks to curb liabilities tied to the financial crisis. It took a $100 million first-quarter charge. The 68 securitization trusts covered by the settlement issued a combined $59.4 billion in mortgage-backed securities from 2005 to 2008, the New York-based bank said yesterday in a statement. The agreement covers 18 investors represented by Gibbs & Bruns LLP and trustees have until June 30 to accept the deal, the law firm said in a separate statement. The accord must be approved by the Federal Housing Finance Agency. Citigroup, the third-biggest U.S. bank, is resolving a portion of liabilities tied to mortgages it packaged and sold to investors in the run-up to the 2008 crisis. JPMorgan Chase & Co. (JPM) and Bank of America Corp. (BAC), the two largest U.S. lenders, previously agreed to multibillion-dollar settlements with Gibbs & Bruns clients. Read the court decision
Read the full story...
Reprinted courtesy of Dakin Campbell, Bloomberg
Mr. Campbell may be contacted at dcampbell27@bloomberg.net

Repair of Fractured Girders Complete at Shuttered Salesforce Transit Center

July 22, 2019 — Nadine M. Post - Engineering News-Record
The repair of two fractured girders spanning Fremont Street and the reinforcement of twin girders spanning First Street are complete at the beleaguered Salesforce Transit Center in San Francisco. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

Office REITs in U.S. Plan the Most Construction in Decade

July 09, 2014 — Brian Louis – Bloomberg
Office buildings in top U.S. markets are getting so expensive that landlords are choosing to build rather than buy, spurring the most development by real estate investment trusts in at least a decade. Office REITs, led by Boston Properties Inc. (BXP), Vornado Realty Trust (VNO) and Kilroy Realty Corp. (KRC), are planning to plow almost $11 billion into new projects, triple the amount just two years ago and the most in data going back to 2004, according to research firm Green Street Advisors Inc. Much of that is focused on the coasts, including San Francisco and New York, the areas with the most demand from both tenants and investors. Prices for office buildings in major markets have surged past peak levels, lifted in part by sovereign-wealth funds and pensions willing to accept lower yields than other investors because they are seeking safe investments. For REITs, which have to answer to shareholders seeking higher returns, building is often a better option than competing with institutional buyers. Read the court decision
Read the full story...
Reprinted courtesy of Brian Louis, Bloomberg
Mr. Louis may be contacted at blouis1@bloomberg.net

Will Maryland Beltway Developer's Exit Doom $7.6B P3 Project?

March 13, 2023 — Jim Parsons - Engineering News-Record
Maryland’s controversial $7.6-billion plan to build tolled express lanes along two Washington, DC-area interstates has suffered a potentially fatal blow with the departure of the private development consortium from the project. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Property Owner Entitled to Rely on Zoning Administrator Advice

May 16, 2018 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In the recent case of In Re Langlois/Novicki Variance Denial, 175 A.3d 1222, 2017 VT 76 (2017), the Vermont court addressed the question of whether a property owner could enforce – by equitable estoppel principles – a representation by a town zoning administrator that no permit or variance was needed for the property owner’s proposed construction. In that case, a landowner wanted to add a pergola to an existing concrete patio on his land. During a social visit at the property, the property owner asked the town zoning administrator if he needed a permit. The town zoning administrator told the property owner that no permit was needed. The property owner thereafter showed the zoning administrator a sketch of the planned construction, and again asked if a permit was required. The town zoning administrator looked at the sketch and repeated his prior advice that no permit was needed. The property owner then spent $33,000 to build the pergola. After incurring the expense, the property owner was advised that the structure violated zoning regulations. The property owner requested a variance, which the zoning board denied. The Court held that the town was estopped from requiring removal of the pergola. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

Federal Defend Trade Secrets Act Enacted

July 14, 2016 — Michael B. McClellan & Jason L. Morris – Newmeyer & Dillion LLP
On May 11, 2016, President Obama signed the Defend Trade Secrets Act (“DTSA”) into law, creating a private federal civil cause of action for trade secret misappropriation. This landmark legislation, a product of bipartisan backing and significant support from the business community, will affect businesses and individuals operating in almost every economic sector across the country. The DTSA will potentially be at issue any time an employee with access to confidential, proprietary, and trade secret information moves on to a competitor or launches a startup that competes with the former employer. This will be true so long as the product or service that the trade secret relates to is either used in or intended for use in interstate or foreign commerce. Under present commerce clause jurisprudence, the vast majority of businesses providing products and services in the United States will be affected by this new law. The DTSA will provide, for the first time, a codified federal civil remedy for misappropriation of trade secrets. Although most states have adopted some version of the Uniform Trade Secrets Act (“UTSA”), there remains significant variation between the states in their application of the UTSA and litigants face significantly different statutory frameworks depending upon which state holds jurisdiction over the dispute. In addition, prior to this new law, litigants were limited to pursuing their claims for misappropriation of trade secrets in state courts, unless federal diversity jurisdiction applied to the dispute. The DTSA changes that dynamic, providing original federal subject matter jurisdiction over trade secret disputes. Reprinted courtesy of Michael B. McClellan, Newmeyer & Dillion and Jason L. Morris, Newmeyer & Dillion Mr. McClellan may be contacted at Michael.mcclellan@ndlf.com Mr. Morris may be contacted at Jason.morris@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES