Construction Contract Basics: No Damages for Delay
May 06, 2024 —
Christopher G. Hill - Construction Law MusingsAfter WAY too long a hiatus, I am back with another in my series of “Construction Contract Basics” posts. In past posts, I’ve covered venue provisions, attorney fee provisions, and indemnity clauses. In this post, I’ll share a few thoughts (or “musings”) on the topic of so-called “no damages for delay” clauses. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the owner or general contractor, is an extension of time to complete the work.
These types of clauses generally make it impossible for a subcontractor (if found in a Subcontract) or Contractor (if found in a Prime Contract) that is delayed through no fault of its own to recover any damages relating to the expenses that are inevitably caused by such delays. Such expenses/damages could include additional supervisory time (including more high-dollar superintendent payments), acceleration costs, demobilization/mobilization costs, and other related expenses. These can add up to real money. Couple that with the inevitable liquidated damages or delay damages that will occur should a contractor or subcontractor cause any delay, and this becomes a very one-sided proposition.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Climate Change a Factor in 'Unprecedented' South Asia Floods
July 18, 2022 —
The Associated Press (Aniruddha Ghosal & Al-Emrun Garjon) - BloombergSylhet, Bangladesh (AP) -- Scientists say climate change is a factor behind the erratic and early rains that triggered unprecedented floods in Bangladesh and northeastern India, killing dozens and making lives miserable for millions of others.
Although the region is no stranger to flooding, it typically takes place later in the year when monsoon rains are well underway.
This year's torrential rainfall lashed the area as early as March. It may take much longer to determine the extent to which climate change played a role in the floods, but scientists say that it has made the monsoon — a seasonable change in weather usually associated with strong rains — more variable over the past decades. This means that much of the rain expected to fall in a year is arriving in a space of weeks.
Read the court decisionRead the full story...Reprinted courtesy of
Bloomberg
Digital Twins – Interview with Cristina Savian
February 11, 2019 —
Aarni Heiskanen - AEC BusinessIn this interview with Cristina Savian, we discuss the present and future of digital twins in the construction industry.
Cristina Savian is the founder and managing director at BE-WISE, a London based consultancy firm specialized in helping start-ups and SMEs to scale-up and bring new technologies into the construction market.
Cristina has over twenty years’ experience in the civil engineering and technology industries, working from small-scale traffic calming and parking schemes in UK and Italy, through to planning major events such as playing a key role as transport manager of the Greenwich Park venue during the London 2012 Olympic and Paralympic Games. She then moved to work for a multinational leading technology company, Autodesk, covering several global roles as technical and commercial lead across Europe and America.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
CSLB Begins Processing Applications for New B-2 License
June 21, 2021 —
Garret Murai - California Construction Law BlogAs we wrote about in our
2021 Construction Law Update, one of the new laws to take effect on January 1, 2021 was the enactment of
SB 1189 which created a new B-2 Residential Remodeling Contractor’s license. The new license is available to contractors working on existing homes with residential wood frame structures requiring at least three (3) unrelated trades or crafts under a single contract.
Beginning June 1, 2021, the Contractors State License Board began accepting applications for the B-2 Residential Remodeling Contractor’s license. According to a press release from the CSLB:
The B-2 classification provides a pathway to licensure for many unlicensed people who are currently working on remodeling and small home improvement projects that don’t qualify for a B-General Building License because the contracted work does not include framing or rough carpentry. Consumers employing a licensed contractor have reduced liability and greater consumer protection. Licensees benefit from licensure as they have opportunities to lawfully advertise, and compete on a level playing field for jobs.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Boyfriend Pleads Guilty in Las Vegas Construction Defect Scam Suicide
November 07, 2012 —
CDJ STAFFOne of the odder twists of the Las Vegas construction defect scandal was the charge that Nancy Quon’s boyfriend helped her in an initial suicide attempt. Quon, implicated by not charged in the case of taking control of homeowner boards in order to profit from construction defect settlements. William Webb was alleged to have bought the drug GBH in order to allow Quon, his girlfriend, to commit suicide. Ms. Quon later overdosed on a combination of alcohol and prescription drugs.
In addition to pleading guilty to the drug charges, Webb also made a plea bargain with prosecutors in which he did not admit guilt in an insurance fraud charge, but acknowledged that prosecutors would likely be successful at obtaining a conviction. Webb will be sentenced February 7 and is expected to receive a sentence of six years imprisonment.
Read the court decisionRead the full story...Reprinted courtesy of
Tips for Drafting Construction Contracts
May 04, 2020 —
Stuart Rosen - Construction ExecutiveWhen negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern.
For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation.
This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations.
Contractor’s liability to the owner for delay damages
It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.”
Reprinted courtesy of
Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Rosen may be contacted at
srosen@proskauer.com
Berlin Lawmakers Get a New Green Workspace
June 21, 2021 —
Iain Rogers - BloombergOn a site steeped in history a few hundred meters from the Reichstag in central Berlin, an office building is rapidly taking shape that handily symbolizes how climate protection has come to dominate the political narrative ahead of September’s election.
The modular Luisenblock West, which will provide working space for Germany’s Bundestag, or lower house of parliament, is mostly wooden beyond a reinforced concrete core. The individual units that make up the bulk of the building are assembled at a site in the east of the city and designed to reduce carbon footprint by capturing thousands of tons of carbon dioxide.
With just four months until the national vote that will mark the end of Angela Merkel’s 16-year reign, the Greens are leading the chancellor’s conservative bloc in some opinion polls and climate protection is high on the list of priorities for many voters. The former fringe party has a real chance of leading a German government for the first time, while traditional parties scramble to affirm their environmental credentials.
Read the court decisionRead the full story...Reprinted courtesy of
Iain Rogers, Bloomberg
Arizona Court of Appeals Rules Issues Were Not Covered in Construction Defect Suit
December 09, 2011 —
CDJ STAFFThe Arizona Court of Appeals has ruled in the case of Peters v. Marque Homes. In this case, Walter Peters provided the land and funding for Marque Homes to build a luxury residence in Glendale, Arizona. By the terms of the “Joint Venture Agreement,” Peters provided the land and funding, while Marque would not charge Peters for overhead, profits, or supervision fees. The agreement specified that profits would be divided equally.
Two years later, Marque sued Peters claiming he had breached his obligations by refusing several offers for the home. Peters replied that Marque had “failed to complete the home so it is habitable to prospective purchasers.” Peters stated he had “retained an expert inspector who had identified numerous defects.” The court appointed a Special Commissioner to list the home for sale. Peters purchased the home with two stipulations ordered by the court. At this point, the earlier case was dismissed with prejudice.
Peters then sued Marque “asserting express and implied warranty claims arising out of alleged construction defects in the home.” Marque claimed that Peters’s claims were “precluded by the prior joint venture dispute.” The court granted Marque’s motion.
The appeals court reversed the lower court’s decision, determining that Peters’s claims were not precluded by the agreement. Although there had been a prior case between the two parties, warranty issues did not form a part of that case. “Peters never raised these allegations nor presented this evidence in support of any warranty claim.”
The court also noted that the “parties never agreed to preclude future warranty claims.” Marque and Peters “agreed in the stipulated sale order that ‘the sale of the property to a third party shall be “as is” with a 10-year structural warranty.’” The court noted that the agreement said nothing about one of the parties buying the house.
The appeals court left open a claim by Marque that there are no implied or express warranties available to Peters. They asked the Superior Court to address this.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of