Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment
December 16, 2019 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government).
Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Court Holds That One-Year SOL Applies to Disgorgement Claims Under B&P Section 7031
November 23, 2020 —
Garret Murai - California Construction Law BlogWe’ve talked before about Business and Professions Code section 7031 which courts have referred to as “harsh[ ],” “unjust[ ]” and even “draconian.” Under Section 7031, a contractor performing work requiring a contractor’s license, but who doesn’t: (1) is prohibited from suing to recover payment for work performed; and (2) is required to disgorge all money paid by the project owner for work performed. This is true even if the project owner knew that the contractor was unlicensed, the contractor was only unlicensed during part of the time it performed work requiring a license, and even if the work performed by the contractor was free of defects. In short, it’s the nuclear bomb of remedies against a contractor.
However, until now, no court has addressed when a project owner is permitted to raise a Business and Professions Code section 7031 claim against a contractor. In the next case, Eisenberg Village of the Los Angeles Jewish Home for the Aging v. Suffolk Construction Company, Inc., Case No B297247 (August 26, 2020), the 2nd District Court Appeal finally answers this question.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Herman Russell's Big Hustle
May 20, 2024 —
Maggie Murphy - Construction Executive“Any person that I knew of in the city of Atlanta who did anything ran it by Herman before they did anything else.”
These are the words of Anthony Dixon, senior project manager and 47-year veteran employee with H. J. Russell & Company. But ask anyone who knows anything about H. J. Russell, and they’ll say the same thing: The story of the company is the story of Herman J. Russell himself.
From humble beginnings in Atlanta’s Summerhill neighborhood came a young man with an unbreakable entrepreneurial spirit, who used that drive to forge an unlikely path to success in the Jim Crow–era South. What began as a plastering company in 1952 is today one of the largest Black-owned contractors in the United States, with Herman’s children—Donata Russell Ross, H. Jerome Russell and Michael B. Russell Sr.—at the helm (a natural fit for the family-focused firm).
Over its 72-year history, H. J. Russell has grown exponentially, contracted when necessary and persevered through segregation, the turbulence of the Civil Rights Movement and multiple economic downturns. Now, in the next five years, they’re poised to become a billion-dollar company.
But long before any of that, there was just a boy and a dream.
Reprinted courtesy of
Maggie Murphy, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Protect Workers From Falls: A Leading Cause of Death
August 14, 2018 —
Mark McGhiey - Construction ExecutiveOne of the leading causes of death for construction workers is falls from elevated surfaces, according to the Bureau of Labor Statistics. In 2016, these accidents accounted for more than 30 percent of all construction fatalities. The top four causes of worker deaths (excluding highway collisions) in the private sector construction industry are:
- falls: 384 (38.7%);
- struck by object: 93 (9.4 percent);
- electrocutions: 82 (8.3 percent); and
- caught-in/between:1 72 (7.3 percent).
One of the most common — and costly — causes of claims occur when construction workers fall from elevated surfaces. These accidents represent more than 30 percent of all construction claim payments.
Reprinted courtesy of
Mark McGhiey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Texas Supreme Court Holds that Invoking Appraisal Provision and Paying Appraisal Amount Does Not Insulate an Insurer from Damages Under the Texas Prompt Payment of Claims Act
September 16, 2019 —
John C. Eichman & Grayson L. Linyard - Hunton Insurance Recovery BlogIn two cases decided June 28, 2019, the Texas Supreme Court held that an insurer’s invocation of a contractual appraisal provision after denying a claim does not as a matter of law insulate it from liability under the Texas Prompt Payment of Claims Act (“TPPCA”). But, on the other hand, the court also held that the insurer’s payment of the appraisal award does not as a matter of law establish its liability under the policy for purposes of TPPCA damages.
In Barbara Techs. Corp. v. State Farm Lloyds, No. 17-0640, 2019 WL 2666484, at *1 (Tex. June 28, 2019), State Farm Lloyds issued property insurance to Barbara Technologies Corporation for a commercial property. A wind and hail storm damaged the property, and Barbara Tech filed a claim under the policy. State Farm denied the claim, asserting that damages were less than the $5,000 deductible.
Barbara Tech filed suit against State Farm, including for violation of the TPPCA. Six months later, State Farm invoked the appraisal provision of the policy. More than a year after the suit was filed, appraisers agreed to a value of $195,345.63. State Farm then paid that amount, minus depreciation and the deductible. Barbara Tech amended its petition to include only TPPCA claims.
Reprinted courtesy of
John C. Eichman, Hunton Andrews Kurth and
Grayson L. Linyard, Hunton Andrews Kurth
Mr. Eichman may be contacted at jeichman@HuntonAK.com
Mr. Linyard may be contacted at glinyard@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Fourth Circuit Holds that a Municipal Stormwater Management Assessment is a Fee and Not a Prohibited Railroad Tax
April 22, 2019 —
Anthony B. Cavender - Gravel2GavelOn February 15, the U.S. Court of Appeals for the Fourth Circuit decided Norfolk Southern Railway Co. v. City of Roanoke, et al.; the Chesapeake Bay Foundation was an Intervenor-Defendant. The Fourth Circuit held that a large stormwater management fee (stated to be $417,000.00 for the year 2017) levied by the City of Roanoke against the railroad to assist in the financing of the City’s permitted municipal stormwater management system was a permissible fee and not a discriminatory tax placed on the railroad.
The Railroad Revitalization and Regulatory Reform Act of 1976 specifically provides that states and localities may not impose any tax that discriminates against a rail carrier, 49 U.S.C. § 11501. Accordingly, the issue confronting the Fourth Circuit was whether the assessment was fee and not a tax.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Insurance Firm Defends against $22 Million Claim
June 15, 2011 —
CDJ STAFFThe Houston law firm of Eggleston & Briscoe successfully defended their client, Colony Insurance Company, which was being sued for $22 million over roof hail damage. The Summer Hill Village Community Association did not convince a jury that the insurance company had violated state law or breached its contract when it denied coverage for the roofs. The homeowners association contended that the roof damage was due to a hail storm in 2007. The jury agreed with experts who contended the damage was already present at that time.
Mr. Eggleston noted that “when your client is sued for a claim of $22 million, it is very satisfying to hear a jury agree that they in fact acted honorably and owed nothing.”
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
The Peak of Hurricane Season Is Here: How to Manage Risks Before They Manage You
September 21, 2020 —
Vincent E. Morgan - Construction ExecutiveThe Atlantic hurricane season runs from June 1 to Nov. 30, but it peaks sharply during August, September and October. The latest forecasts predict this will be one of the most active seasons in history, in terms of frequency and severity, though it is always important to remember that even a single hurricane or tropical storm making landfall can still be a devastating event.
Hurricanes pose unique risks to the construction industry ranging from project and labor force disruptions to concerns about the availability and price of construction materials. This is even more true this year, which requires merging hurricane preparedness and response plans with the realities of COVID-19. Because hurricanes cannot be avoided, preparing for them is the only way to manage these risks. Ensuring the personal safety and wellbeing of affected individuals is the first priority. After that, here are some key issues, and suggestions for handling them, that may help guide construction companies through the storm.
SITE PROTECTION
Construction contracts often place responsibility for site protection on contractors. Where those duties exist, failing to properly carry them out can lead to enormous losses that then turn into liability claims. This could be anything from removing materials that can become projectiles, covering exposed ventilation shafts, and sealing electrical conduits to ensuring that key equipment such as generators and pumps can remain functional in a storm. One way to approach it is to imagine sustained 100-mph winds and relentless water, and then make sure preparedness efforts are likely to survive that kind of test. This is not the time for guessing. It is far better to go through a rigorous analytical process now than in a courtroom years later.
Reprinted courtesy of
Vincent E. Morgan, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of