Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)
October 05, 2020 —
Christopher G. Hill - Construction Law MusingsI’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:
White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Is Construction in Arizona Back to Normal?
September 10, 2014 —
William M. Kaufman – Construction Lawyers BlogThe Phoenix Metro area is finally pulling out of the Great Recession of 2008. Potential homebuyers are frantically looking to buy a home before interest rates rise and prices continue their ascent to normalcy. For the last several months, residential construction builders have continued to buy more land around the Valley of the Sun for new subdivisions, especially in North Phoenix and the East Valley. In fact, from January through May of 2013, in the Phoenix Metro area alone, 86 new communities have come to fruition—more than all of 2012. Nationally, single-family housing starts reached 667,000 in December 2013 according to the National Association of Home Builders tracking of single-family home starts, which is comparable to 1985 levels.
It has been well documented that since the conclusion of World War II, Arizona’s population growth fostered new home construction at a rapid, almost unmatched pace. At the 2006 construction peak, Arizona’s residential construction output climbed to 64,000, more than double the average 20,000 to 30,000 new homes that are typically constructed annually. Building rates have not come close to the 2006 numbers, but new home starts increased 70 percent since 2012.
So after six years after the real estate bubble popped, is the construction industry in Arizona finally back to normal? It depends on your definition of “normal.”
In 2009, foreclosures reached alarming proportions. However, in 2010, the engine of Arizona’s population growth, the Phoenix Metro area, began to grow again. Since 2010, Maricopa County had added 125,000 residents. There is strong demand for new housing, and appreciating housing prices has let the construction industry get back on its feet. In residential construction, supply is tight, and all cash offers are common. We all know that Wall Street played a huge role in creating the housing bubble, and eventual bust, by facilitating the use of risky, sub-prime mortgages and turning them into securities that were sold to investors, pension-funds, and the like.
Reprinted courtesy of
William M. Kaufman, Lockhart Park LP
Mr. Kaufman may be contacted at wkaufman@lockhartpark.com, and you may visit the firm's website at www.lockhartpark.com
Read the court decisionRead the full story...Reprinted courtesy of
While Construction Permits Slowly Rise, Construction Starts and Completions in California Are Stagnant
December 05, 2022 —
John Kazanovicz & Jason Feld - Kahana FeldThere is an interesting phenomenon happening in the California construction market since the Summer of 2022. There is a steady but slow rise in the construction building permits being issued throughout California. According to the U.S. Census and the U.S. Department of Housing and Urban Development’s joint announcement (https://www.census.gov/construction/nrc/pdf/newresconst.pdf) of new residential construction statistics for September 2022, privately‐owned housing units authorized by building permits in September were at a seasonally adjusted annual rate of 1,564,000. This is 1.4 percent above the revised August rate of 1,542,000. While this is slightly lower than a year ago (3.2 percent below the September 2021 rate of 1,615,000), the trend for obtaining new home permits was reportedly ahead of the projected rates given the market conditions and inflation throughout the country. Interestingly, single‐family authorizations in September were at a rate of 872,000 which was also 3.1 percent below the revised August 2022 figure of 900,000. Authorizations of units in buildings with five units or more were at a rate of 644,000 in September. Overall, while slowly recovering from the record lows during the height of the pandemic, the economic forecast for new home construction in California is positive, but cautious.
The flip side of this coin is the construction starts in California, which continue to remain stagnant despite additional building permits being issued. Privately‐owned housing starts in September were at a seasonally adjusted annual rate of 1,439,000. This is 8.1 percent (±14.9 percent) below the revised August estimate of 1,566,000 and is 7.7 percent (±11.5 percent) below the September 2021 rate of 1,559,000. Single‐family housing starts in September were at a rate of 892,000; this is 4.7 percent (±10.7 percent) below the revised August figure of 936,000. The September rate for units in buildings with five units or more was 530,000.
Reprinted courtesy of
John Kazanovicz, Kahana Feld and
Jason Feld, Kahana Feld
Mr. Kazanovicz may be contacted at jkazanovicz@kahanafeld.com
Mr. Feld may be contacted at jfeld@kahanafeld.com
Read the court decisionRead the full story...Reprinted courtesy of
New York Appellate Court Holds Insurers May Suffer Consequences of Delayed Payment of Energy Company Property and Business Interruption Claims
March 16, 2020 —
Syed S. Ahmad & Geoffrey B. Fehling - Hunton Andrews KurthA New York appellate court recently held that renewable bio-diesel fuel manufacturer BioEnergy Development Group LLC may pursue tens of millions of dollars in damages from its insurers under two all-risk insurance policies, including amounts in excess of the policy limits, where the insurers refused to pay claims in a timely manner.
BioEnergy purchased two all-risk property policies from Lloyd’s to provide coverage for its manufacturing plant in Memphis, Tennessee. A fire destroyed the Memphis plant in March 2016, eliminating BioEnergy’s production capacity and sole source of revenue. BioEnergy made claims under the policies and sought to rebuild its plant. The insurers acknowledged coverage and eventually made approximately $8 million in interim payments, but the parties disagreed over the value of the total property damage claim, which BioEnergy contended was in excess of $24 million. The disputed claim was submitted to appraisal, which resulted in the insurers agreeing to pay the full business interruption limit of $15.1 million.
The insurers filed a declaratory judgment lawsuit, however, seeking to limit BioEnergy’s recovery to the policy limits of $15.1 million. BioEnergy alleged that the insurers failed to make interim payments in a timely manner after the fire and, as a result, the company suffered increased losses because it could not rebuild without the insurance proceeds. BioEnergy sought actual and consequential damages, plus attorneys’ fees, arising from the delayed payments, including payment of its business interruption losses in excess of the policy limits.
Reprinted courtesy of
Syed S. Ahmad, Hunton Andrews Kurth and
Geoffrey B. Fehling, Hunton Andrews Kurth
Mr. Ahmad may be contacted at sahmad@HuntonAK.com
Mr. Fehling may be contacted at gfehling@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Payne & Fears LLP Recognized by U.S. News & World Report and Best Lawyers in 2023 “Best Law Firms” Rankings
November 28, 2022 —
Payne & Fears LLPPayne & Fears LLP is pleased to announce that the firm has been recognized by U.S. News & World Report and Best Lawyers 2023 “Best Law Firms” list. Firms included in the 2023 edition of U.S. News – Best Lawyers “Best Law Firms” are recognized for professional excellence with consistently impressive ratings from clients and peers. This includes the top 5% of private practicing lawyers in the United States.
Payne & Fears LLP has been ranked in the following practice areas:
- Commercial Litigation
- Employment Law – Management
- Insurance Law
- Labor Law – Management
- Litigation – Labor & Employment
- Litigation – Real Estate
- Litigation – Intellectual Property
Additionally, on August 15, 2022, 11 of our attorneys were selected for inclusion in
The Best Lawyers in America® 2023. Collectively bringing decades of experience and dedication to their practice, Jeffrey K. Brown, Daniel F. Fears, Daniel M. Livingston, Thomas L. Vincent, Benjamin A. Nix, James L. Payne, Scott S. Thomas, and Kelby Van Patten received this respected achievement. Additionally, Leilani E. Jones, Sarah J. Odia, and Matthew C. Lewis were included in Best Lawyers: Ones to Watch 2023.
Read the court decisionRead the full story...Reprinted courtesy of
Payne & Fears LLP
Bidder Be Thoughtful: The Impacts of Disclaimers in Pre-Bid Reports
August 04, 2021 —
Joshua A. Morehouse - ConsensusDocsWhen bidding a project, subsurface or latent site conditions that are not immediately apparent can massively impact the costs of performance to general contractors. Were contractors required to bid on projects without any information on pre-existing conditions, they would need either to be assured that any additional costs would be reimbursed by the owner, or to include significant contingencies for subsurface conditions in their bids. For owners, these options result in either increased risk or increased cost—neither of which is particularly palatable. Owners therefore implement several contractual tools to minimize these risks and costs.
One of these tools is providing bidders with a report on latent conditions, often called a “geotechnical data report” or “GDR”, but otherwise shifting as much of the subsurface-related risk as possible to the contractor. In theory, these reports permit contractors to appropriately adjust their contingencies for latent conditions, thus saving owners money. However, several independent and thorny issues arise where site reports provided by the owner are either inconsistent with or silent on the actual conditions of a project site. Hence owners often include disclaimers with these reports, such as noting that the report is for “informational purposes only” or that the report is “not part of the contract documents."
Read the court decisionRead the full story...Reprinted courtesy of
Joshua A. Morehouse, Peckar & Abramson, P.C.Mr. Morehouse may be contacted at
jmorehouse@pecklaw.com
Five LEED and Green Construction Trends to Watch in 2020
January 27, 2020 —
Tommy Linstroth - Construction ExecutiveTo succeed in any field, you can never stop learning—especially in the green construction industry where standards and technology are always growing and changing.
Here are a few of the exciting trends in LEED certification and green construction learned about during this year’s Greenbuild International Conference and Expo, which is the largest annual event for green building professionals in the world.
1. More Transparency About Products
In 2020, the product sustainability information provided by manufacturers will continue becoming more transparent and accessible. Manufacturers are coming to the table and presenting more useful information on environmental and health impacts, conducting life cycle analyses and making the information available for the design and construction marketplace.
Although this means even more information for construction and design teams to take into account when planning green construction projects, it’s a definite positive. We’re starting to see the actual environmental performance getting taken into account in product specification.
Reprinted courtesy of
Tommy Linstroth, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Travelers’ 3rd Circ. Win Curbs Insurers’ Asbestos Exposure
May 03, 2017 —
Gregory D. Podolak - Saxe Doernberger & Vita, P.C.In breaking news this week, LAW360.com posted that the Third Circuit ruled Friday that “a common exclusion found in a Travelers policy bars coverage for claims arising out of asbestos in any form, limiting insurers’ potential exposure to asbestos injury claims by precluding policyholders from arguing that the exclusionary language is ambiguous and doesn’t extend to products containing the carcinogen.”
In its detailed analysis of the decision, LAW360 turned to Greg Podolak for his analysis.
Gregory D. Podolak, managing partner of Saxe Doernberger & Vita PC’s Southeast office, said the ruling is a cautionary tale that should galvanize policyholders and their insurance brokers to take a closer look at policies to delete or curtail broad “arising out of” language in exclusions. Otherwise, insureds could find themselves without any coverage for claims even remotely related to a certain product, he said.
Read the court decisionRead the full story...Reprinted courtesy of
Gregory D. Podolak, Saxe Doernberger & Vita, P.C.Mr. Podolak may be contacted at
gdp@sdvlaw.com