Does a Broker Forfeit His or Her Commission for Technical Non-Compliance with Department of Real Estate Statutory Requirements?
September 14, 2020 —
Kevin J. Parker - Snell & Wilmer Real Estate Litigation BlogIn a recent Arizona Court of Appeals case, CK Revocable Trust v. My Home Group Real Estate LLC, 2020 WL 4306183 (7/28/2020), the Court of Appeals addressed the distinction between “substantive” and “technical” statutory requirements for real estate broker commission agreements.
The Court explained that failure to comply with a substantive requirement would preclude the broker from recovering a commission, but failure to comply with a technical requirement would not. As examples of such substantive requirements, the Court identified the statutory requirement that the broker be licensed at the time the claim for commission arose, and the statutory requirement that the listing agreement be signed by both the broker and the client.
Read the court decisionRead the full story...Reprinted courtesy of
Kevin J. Parker, Snell & WilmerMr. Parker may be contacted at
kparker@swlaw.com
Apartment Investors Turn to Suburbs After Crowding Cities
March 12, 2015 —
Nadja Brandt and Oshrat Carmiel – Bloomberg(Bloomberg) -- Real estate investor Robert Hart pulled into the lot of a 400-unit apartment community in a San Diego suburb last month, prepared to pay up for the recently completed project on a quiet residential street. A competitor from a publicly traded landlord was already there, he said.
“It was on the one hand reassuring to know that we were both chasing the same opportunity,” said Hart, president and chief executive officer of closely held TruAmerica Multifamily. “On the other hand, it reinforced my opinion that large institutional real estate investors will be chasing yield far beyond the urban core.”
Reprinted courtesy of
Nadja Brandt, Bloomberg and
Oshrat Carmiel, Bloomberg
Ms. Brandt may be contacted at nbrandt@bloomberg.net
Ms. Carmiel may be contacted at ocarmiel1@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
New OSHA Rule Creates Electronic Reporting Requirement
June 22, 2016 —
John K. Baker & Kevin Conrad – White and Williams LLPThe United States Occupational Safety and Health Administration (OSHA) issued a
Final Rule revising portions of its Recording and Reporting Occupational Injuries and Illnesses regulations (Recording and Reporting Regulations). The revisions take effect August 10, 2016.
Employers subject to the new requirements have until July 1, 2017 to submit electronically the required information for calendar year 2016. OSHA will make electronically-submitted workplace-safety data for each reporting employer available publicly in an online database.
Reprinted courtesy of
John K. Baker, White and Williams LLP and
Kevin Conrad, White and Williams LLP
Mr. Baker may be contacted at bakerj@whiteandwilliams.com
Mr. Conrad may be contacted at conradk@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Design-Build Contracting: Is the Shine Off the Apple?
March 09, 2020 —
John P. Ahlers - Ahlers Cressman & Sleight PLLCThe design-build delivery method offers many benefits to owners. Among the cited benefits are that projects are generally completed faster, at a lower cost, by allowing innovative approaches through early and continual contractor involvement in the design process. The design contractor serves as a single point of contact responsible for both the design and construction of the project.
The Washington State Department of Transportation (“WSDOT”) utilized the design-build procurement method on the largest project ($2 billion) of its type in the state of Washington: the Highway 99 Tunnel, which was finished almost three years late after the tunnel-boring machine (“Bertha”) broke down six years ago. The sorted tale of the SR-99 Tunnel Project was the source of many of this firm’s blog articles.[1] The State of Washington staunchly maintained that the design-build contract protected its taxpayers from covering the repair costs to the tunnel-boring machine when it broke down in 2013. Bertha did not resume tunneling for almost two years, putting on hold removal of the Alaska Way viaduct and rebuilding of the Seattle Waterfront without an elevated highway.
In December 2013, the contractor for the project, Seattle Tunnel Partners (“STP”), contended that a 110-foot long 8” steel pipe which Bertha hit caused the breakdown. That pipe had been installed for groundwater testing by WSDOT in 2002 during its preliminary engineering for the viaduct replacement project. The project’s Dispute Review Board (“DRB”) composed of three tunneling experts found that the pipe constituted a “differing site condition” for which the State was responsible to disclose to contractors. The Board, whose views were non-binding, did not opine about how much damage the undisclosed pipe cost.[2] In other words, the mere fact that a differing site condition occurred did not establish that there was a causal connection between the damages which STP was seeking (in excess of $600 million) and the differing site condition (the 8” steel pipe which WSDOT lawyers at trial derisively referred to as “nothing more than a toothpick for Bertha’s massive cutter head”). STP maintained that Bertha had made steady progress except for three days immediately after hitting the pipe. It didn’t help the contractors’ case that during the discovery phase of the two-month trial, WSDOT lawyers uncovered documents showing that the contractor’s tunnel workers encountered and logged the pipe before digging began.[3]
Read the court decisionRead the full story...Reprinted courtesy of
John P. Ahlers, Ahlers Cressman & Sleight PLLCMr. Ahlers may be contacted at
john.ahlers@acslawyers.com
“But it’s 2021!” Service of Motion to Vacate Via Email Found Insufficient by the Eleventh Circuit
June 21, 2021 —
Justin K. Fortescue - White and WilliamsWhile we are all getting used to the “new normal” of working remotely and relying on emails for almost all communications, a recent decision from the United States Court of Appeals for the Eleventh Circuit provides arbitration practitioners with a stark reminder – the “notice” requirements of the Federal Arbitration Act (FAA) will be strictly enforced and providing notice of a motion to vacate via email may not qualify as proper service.
In O'Neal Constructors, LLC v. DRT Am., LLC, 991 F.3d 1376 (11th Cir. 2021), O’Neal Constructors, LLC (O’Neal) and DRT America (DRT) entered into a contract containing an arbitration provision. Following a dispute, the parties went to arbitration and, on January 7, 2019, the panel issued an award requiring DRT to pay O’Neal a total of $1,415,193. The amount awarded to O’Neal consisted of two parts: $765,102 for the underlying contract dispute and $650,090 for reimbursement of O’Neal’s attorneys’ fees. While DRT paid O’Neal the first portion of the award, DRT refused to pay the portion that related to O’Neal’s attorneys’ fees.
On April 4, 2019, as a result of DRT’s refusal to pay O’Neal’s attorneys’ fees, O’Neal filed a motion to confirm the award in Georgia state court (which was subsequently removed to the Northern District of Georgia). The next day, in a separate action, DRT filed a motion to vacate the attorneys’ fees portion of the award and, that same night, DRT’s counsel emailed O’Neal’s counsel a “courtesy copy” of DRT’s memorandum in support of the motion to vacate. A few weeks later, on April 30, 2019 (i.e., more than three months after the award was issued), DRT served O’Neal (via U.S. Marshall) with a copy of the motion to vacate.
Read the court decisionRead the full story...Reprinted courtesy of
Justin Fortescue, White and WilliamsMr. Fortescue may be contacted at
fortescuej@whiteandwilliams.com
7 Sustainability Ideas for Modular Classrooms in the Education Industry (guest post)
June 10, 2015 —
Melissa Dewey Brumback – Construction Law in North CarolinaToday, a guest post on sustainable modular classrooms from Kathy Werder, a freelance architect by profession and a researcher by nature. According to Kathy, most of her research papers focus on promoting integration that leads to sustainable and lean design and construction practices. Kathy is obsessed with the latest rage in the construction industry – modular building solutions. She is also an avid writer, and loves blogging about green buildings and portable construction units. Welcome, Kathy!
According to Wikipedia, a sustainable building refers to “ a structure and using process that is environmentally responsible and resource-efficient throughout a building’s life-cycle from sitting, to design, construction, operation, maintenance, renovation, and demolition.”
So if we accept this definition to be true, in order to make an actual sustainable building we have to consider the entire process of building right from the blueprint stage all the way to demolition, and ensure that at every step of the way there is minimal or no negative impact on the environment, especially in terms of resource efficiency.
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Construction Law in North CarolinaMs. Brumback may be contacted at
mbrumback@rl-law.com
Contractor’s Burden When It Comes to Delay
October 26, 2020 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:
When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.
Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Five-Year Statute of Limitations on Performance-Type Surety Bonds
December 01, 2017 —
David Adelstein - Florida Construction Legal UpdatesThe statute of limitations on a claim against a performance-type bond is 5 years from the breach of the bond, i.e., the bond-principal’s default (based on the same statute of limitations that governs written contracts / obligations). See Fla. Stat. s. 95.11(2)(b). This 5-year statute of limitations is NOT extended and does NOT commence when the surety denies the claim. It commences upon the default of the bond-principal, which would be the act constituting the breach of the bond. This does not mean that the statute of limitations starts when a latent defect is discovered. This is not the case. In dealing with a completed project, the five-year statute of limitations would run when the obligee (beneficiary of the bond) accepted the work. See Federal Insurance Co. v. Southwest Florida Retirement Center, Inc., 707 So.2d 1119, 1121-22 (Fla. 1998).
This 5-year statute of limitations on performance-type surety bonds has recently been explained by the Second District in Lexicon Ins. Co. v. City of Cape Coral, Florida, 42 Fla. L. Weekly D2521a (Fla. 2d DCA 2017), a case where a developer planned on developing a single-family subdivision.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
