Presenting a “Total Time” Delay Claim Is Not Sufficient
September 12, 2022 —
David Adelstein - Florida Construction Legal UpdatesWhen presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss.
In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Home-Building Climate Warms in U.S. as Weather Funk Lifts
May 20, 2015 —
Sho Chandra and Steve Matthews – BloombergThe surge in April housing starts sends a clear signal that bad weather was the root cause of weak readings in the first quarter. The question now is whether the rebound is strong enough to lift the world’s largest economy.
Builders broke ground on 1.14 million homes at an annualized rate last month, the most since November 2007 and up 20.2 percent from March, figures from the Commerce Department showed Tuesday in Washington. It was the single-biggest monthly surge since 1991, with both the Northeast and Midwest taking part, clearly showing milder temperatures had a hand.
The rebound in home building is shaping up to be large enough to make a meaningful contribution to economic growth this quarter. Nonetheless, because residential construction accounts for less than 4 percent of the economy, it would take big gains to make up for what’s likely to be sustained weakness in manufacturing caused by slowing exports and cuts in business investment by the energy industry.
Reprinted courtesy of
Sho Chandra, Bloomberg and
Steve Matthews, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Grad Student Sues UC Santa Cruz over Mold in Residence
November 13, 2013 —
CDJ STAFFMatthew Richert, a graduate student at UC Santa Cruz, and his wife have filed a lawsuit against UC Santa Cruz, alleging the residence they rented from the university was contaminated with mold, causing problems for them and their children.
The family noticed the signs of mold on the walls, but did not initially connect it with their daughter’s health problems, until they mentioned it to their doctor. The doctor sent a letter to the university requesting that the family be transferred to another unit if the mold problem could not be remedied. Mr. Richert made five such requests.
Eventually the university moved the family to a hotel as they investigated the unit. The Richert’s unit remains unoccupied, and a Santa Cruz spokesperson noted that 60 of the units showed mold problems.
Read the court decisionRead the full story...Reprinted courtesy of
Performing Work with a Suspended CSLB License Costs Big: Subcontractor Faces $18,000,000 Disgorgement
September 17, 2015 —
Steven M. Cvitanovic & David A. Harris – Haight Brown & Bonesteel LLPIn what could lead to a draconian result, the Court of Appeal for the First Appellate District held that a contractor who performs work without a valid license can be required to disgorge all payments received, even if the contractor perfectly performed its work. The case, Judicial Council of California v. Jacobs Facilities, Inc. (Ct. of Appeal, 1st App. Dis., Div. One, A140890, A141393), involved an $18,000,000 contract between Jacobs Facilities, Inc. (“Jacobs Facilities”) and the Judicial Council of California (“Judicial Council”). In April 2006, Jacobs Facilities, a wholly owned subsidiary of Jacobs Engineering Group, Inc. (“Jacobs Engineering”) entered into a three year contract with the Judicial Counsel to maintain 121 courthouses and other judicial branch buildings throughout Southern California (the “Contract”). Jacobs Facilities contracted to provide maintenance and oversight services, while retaining subcontractors to perform the actual maintenance and repair work.
In December 2006, as part of a corporate reorganization, Jacobs Engineering started winding up Jacobs Facilities and transferred its employees to Jacobs Engineering and then subsequently to another wholly owned subsidiary called Jacobs Project Management Co. (“Jacobs Management”). The work that was performed by Jacobs Facilities was taken over by Jacobs Management. As part of the windup, Jacobs Facilities’ Contractor’s State License Board license was allowed to lapse and the license expired by operation of law in November 2008. Although Jacobs Management was now performing the work, it was not added as a party to the contract. Although it appears Judicial Council was aware of the corporate changes, it was not until November 2009 that the parties assigned the contract to Jacobs Management.
Reprinted courtesy of
Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and
David A. Harris, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com
Mr. Harris may be contacted at dharris@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Virginia Tech Has Its Own Construction Boom
May 10, 2013 —
CDJ STAFFThe last few years has been a tough time for the construction industry, unless you’re in the proximity to the campus of Virginia Tech. Since 1999, the school has seen more than $1 billion in construction projects. Charles Steger, the president of the university says that “we have no intention of slowing down.”
Steger views some of the construction as vital to the school’s mission, noting that at Davidson Hall, which contains chemistry laboratories, “the wiring and other facilities were almost a health hazard.” The building is undergoing a $31 million renovation.
In order to keep the campus walkable, parking lots are being replaced by parking garages. Four dormitory buildings will be demolished and replaced by new facilities. Funds for the development have come from a mix of student fees, donations, research revenues, bond issues, and taxpayer revenues.
Read the court decisionRead the full story...Reprinted courtesy of
Homeowner’s Policy Excludes Coverage for Loss Caused by Chinese Drywall
November 18, 2011 —
Tred R. Eyerly - Insurance Law HawaiiExclusions barred the homeowners from recovering for losses caused by Chinese drywall in their home. Ross v. C. Adams Const. & Design, L.L.C., 2011 La. App. LEXIS 769 (La. Ct. App., released for publication Oct. 5, 2011).
Two years after purchasing their home, the Rosses began experiencing chronic malfunctions in the heating, ventilation and air conditioning system. After discovering the presence of gypsum drywall, or "Chinese drywall", they submitted a claim to their insurer, Louisiana Citizens Property Insurance Company, for damages caused by the Chinese drywall. Louisiana Citizens denied the claim.
The Rosses sued. The trial court granted summary judgment to Louisiana Citizens based upon exclusions in the policy.
On appeal, the appellate court first agreed the Rosses had sustained a direct physical loss. The inherent qualities of the Chinese drywall created a physical loss to the home and the drywall had to be removed and replaced.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
Supreme Court Grants Petition for Review Regarding Necessary Parties in Lien Foreclosure Actions
August 17, 2017 —
Lindsay K. Taft - Ahlers & Cressman PLLCFor several years, the requirements for which parties must be named in a lien foreclosure action when a release of lien bond is in place have been cloudy. RCW 60.04 et seq., the “mechanics’ lien” or “construction lien” statute, provides protection for a party or person who provides labor, materials, or equipment to a construction project. That person or party, if not paid, can file a lien against the construction project property to secure recovery. As the lien impacts the property by “clouding title” and could potentially result in foreclosure of the property, the statute sets forth strict requirements with respect to timing, notice, and parties. For example, the lien must be recorded within 90 days of the person or party’s last day of work or materials or equipment supplied, and the lien claimant must then give a copy of the claim of lien to the owner or reputed owner within 14 days of the lien recording. RCW 60.04.081.
The statute also allows a property owner or other party to “free” the property from the lien prior to the claim being resolved by issuing a release of lien bond. While the claim is still in dispute, the lien then attaches to the bond and not the property. The same rules about foreclosure, however, still apply but not without some confusion.
Read the court decisionRead the full story...Reprinted courtesy of
Lindsay K. Taft, Ahlers & Cressman PLLCMs. Taft may be contacted at
ltaft@ac-lawyers.com
ConsensusDOCS Updates its Forms
October 21, 2015 —
Christopher G. Hill – Construction Law MusingsAs reported recently in ENR Magazine, among other publications, the ConsensusDOCS folks have updated their contract forms. Why is this news?
First of all, it’s only been around three and a half years since these documents were officially released and this release is about 18 months sooner than anticipated (the original revision cycle was to be 5 years). Why the revision? According to my friend and counsel to ConsensusDOCS, Brian Perlberg, one major rationale is that “the economics of the construction industry today looks nothing like it did [in 2007.”
Among the changes are several terminology changes (“constructor” instead of “contractor” for instance), the addition of mandatory green building design as a basic service (these forms already have a Green Building Addendum) if included in the Owner’s plan and the ability to provide for prevailing party attorney fees (before both sides of a dispute bore their own fees).
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com