Seattle Washington Building Expert Directory

California Expands on Scope of Coverage for Soft Cost Claims

February 14, 2023 — Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.
The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage. The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project. As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.
Ms. Rabiyan may be contacted at CRabiyan@sdvlaw.com

Sales of New U.S. Homes Fell in February to Five-Month Low

March 26, 2014 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. fell in February to the lowest level in five months, a sign the industry may take time to pick up after inclement weather damped demand earlier in the year. Sales declined 3.3 percent to a 440,000 annualized pace, following a 455,000 rate in the prior month that was the strongest in a year, figures from the Commerce Department showed today in Washington. The median forecast of 77 economists surveyed by Bloomberg called for 445,000. Unusually frigid temperatures added to restraints including rising mortgage rates, higher property values, and a lack of supply that kept prospective buyers away from the market for new and existing properties. Bigger gains in employment and consumer sentiment would help spur the recovery in homebuilding, sustaining its contribution to economic growth and boosting earnings at companies such as Lennar Corp. and KB Home. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted at schandra1@bloomberg.net

Wisconsin Supreme Court Abandons "Integrated Systems Analysis" for Determining Property Damage

September 12, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The Wisconsin Supreme Court departed from its previous mechanism for determining property damage under the "integrated systems analysis" and found the insurers were not entitled to summary judgment as determined by the trial court. 5 Walworth, LLC v. Engerman Contracting, Inc., 2023 Wis. LEXIS 152 (Wis. June 20, 2023). 5 Walworth LLC hired Engerman as general contractor to construct a swimming pool complex. Engerman subcontracted with Downes Swimming Pool Co., Inc. to construct the pool complex. Otto Jacobs supplied Downes with a ready-mixed concrete called shotcrete, commonly used in swimming poll construction. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Connecticut Supreme Court Finds Faulty Work By Subcontractor Constitutes "Occurrence"

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The U.S. District Court in Alabama certified a question to the Connecticut Supreme Court: Is damage to a project caused by faulty workmanship "property damage" resulting from an "occurrence"? With some qualification, the Connecticut Supreme Court answered in the affirmative. Capstone Building Corp. v. Am. Motorists Ins. Co., SC 18886 (Conn. June 11, 2013). Captsone Development agreed to coordinate and supervise construction on a building at the University of Conneticut. Capstone Building was the general contractor. UConn secured an OCIP policy from American Motorist Insurance Company ("AMICO"). More than three years after completion, UConn notified the insureds of alleged defects in the project, including elevated levels of carbon monoxide. The source of the leak was the individual hot water heaters in residential units and insufficient draft of exhaust from the heater.Other defects were found during an investigation. The insureds tendered to AMICO. Coverage was denied because the liability arose out of the insureds' own work.The insureds settled with UConn, paying $1 million each. The insureds then sued AMICO in Alabama and the question was certified to the Connecticut Supreme Court. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

A Survey of New Texas Environmental Laws

December 30, 2019 — Anthony B. Cavender - Gravel2Gavel
This is a brief survey of many of the environmental and regulatory laws passed by the Texas Legislature and signed by the Governor in the 86th Regular Session of the Legislature, which ended in May 2019. Altogether, more than 1,300 laws were enacted in this session, including a surprising number of environmentally related bills. Most of these new laws take effect on September 1, 2019. This survey places them in the following broad categories: Air, Water; Waste; Disaster (principally because of the effects of Hurricane Harvey); and Miscellaneous. (Special thanks to Jay Bowlby, a summer intern in our Houston office, who made a significant contribution to this survey.) 1. Air HB 1627—amends Section 386.001(2) of the Health and Safety Code to remove several counties from the list of counties with deteriorating air quality subject to the Texas Emissions Reductions Plan. HB 1346—relates to the diesel emissions reductions incentives and gives the TCEQ flexibility in administering this program. HB 2726—concerns amended air quality permit applications. The law provides that construction of a project may proceed, at the applicant’s own risk, after the TCEQ Executive Director has issued a draft permit including the permit amendment. However, this provision does not apply to a permit amendment affecting a concrete batch plant located within 888 yards of a residence. HB 3725—creates the Texas Emissions Reduction Plan Trust Fund, which will be held by the Comptroller and administered by the TCEQ, which also administers the TERP program. SB 698—authorizes the TCEQ to provide expedited processing of certain Texas Clean Air Act permit applications by increasing the agency’s permitting staff. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Judge Who Oversees Mass. Asbestos Docket Takes New Role As Chief Justice of Superior Court

January 02, 2024 — Lewis Brisbois Newsroom
Boston, Mass. (December 13, 2023) - Judge Michael Ricciuti, who presides over the Massachusetts state asbestos litigation docket, has been appointed to a new role as Chief Justice of Massachusetts Superior Court, effective December 22, 2023. The appointment is expected to result in the end of his tenure overseeing the state asbestos litigation. Judge Ricciuti was appointed by Governor Charlie Baker to the Superior Court in 2017. He has served in five counties and serves six-month rotations in the Business Litigation Session, in addition to his role overseeing the Massachusetts Asbestos Litigation docket. His current committee participation includes serving on the Superior Court Judicial Education Committee and the Supreme Judicial Court Advisory Committee on Massachusetts Evidence Law. He also serves as a judicial mentor. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Harlem Developers Reach Deal with Attorney General

February 25, 2014 — Beverley BevenFlorez-CDJ STAFF
Joseph Scarpinito and Shiraz Sanjana, developers of the Mirada condominium in Harlem, New York can avoid a contempt charge from state Attorney General Eric Schneiderman, “if they make the required repairs and obtain a permanent certificate of occupancy at the property,” according to The Real Deal. Scarpinito and Sanjana “agreed to deposit $200,000 into an escrow account and make repairs to stop flooding and other defects at the 161 East 110th Street condo, which are required to obtain a certificate of occupancy from the city Department of Buildings.” Last December, the Attorney General “filed suit against the developers, alleging they submitted false filings to his office in claiming that Scarpinito’s 83-year-old mother was the actual developer of the 68-unit condo.” Furthermore, the condo board lawyers submitted a complaint to Schneiderman “detailing extensive defects in the building, including water leaks entering the building from the roof and façade.” The developers have been ordered “to submit weekly reports to the AG’s office detailing progress on the repairs and obtaining the certificate of occupancy.” Read the court decision
Read the full story...
Reprinted courtesy of

Erector Tops Out 850-Foot-Tall Rainier Square Tower in Only 10 Months

September 23, 2019 — Nadine M. Post - Engineering News-Record
As predicted, the Erection Co. topped out Seattle’s 850-ft-tall Rainier Square Tower, with its radical composite steel frame dubbed “speed core,” in only 10 months. Steel erection began last October in the lowest basement. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES