Differences in Types of Damages Matter
June 22, 2016 —
Christopher G. Hill – Construction Law MusingsOver the last 7 and a half years (yes I have been doing this for that long), I have often “mused” on various contractual provisions and their application. Why? Because
the contract matters and will be enforced. Provisions like “no damages for delay” and “
pay if paid” litter construction contracts and will be enforced if properly drafted. These types of clauses affect whether and what types of damages you as a construction company can collect.
Of course, these clauses have their limitations. For instance, and as
pointed out by my pal Matt DeVries at his great Best Practices Construction Law blog, not all damages that a subcontractor or general contractor may attribute to coordination or other scheduling related issues are “delay damages” to which a “no damages for delay” clause may apply.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Court Grants Summary Judgment to Insurer in HVAC Defect Case
August 04, 2011 —
CDJ STAFFThe US District Court in Colorado has determined in the case of RK Mechanical, Inc. v. Travelers Property Casualty Company of America that Travelers did not breach its insurance contract when it refused to cover RK Mechanical.
RK Mechanical performed an HVAC installation for a residential project for which J.E. Dunn Rocky Mountain was the general contractor. As part of the work, RK “installed approximately one hundred seventy-one CPVC flanges, which were manufactured by Charlotte Pipe and Foundry Company.” Two of these flanges failed in June, 2009 leading to water damage. RK replaced the cracked flanges and engaged in water remediation. “Travelers paid Dunn and RK for the costs associated with the water damage associated with the Flange Failure.” The court notes that Travelers did not pay for the cracked flanges, however.
Subsequently, RK examined the remaining flanges, finding many cracked ones. These were replaced with new ones. Later, all the Charlotte flanges were replaced with ones from another manufacturer. RK applied for coverage.
All sides brought in their experts: “Microbac Laboratories, Inc. prepared a report on behalf of RK concluding that the Flange Failure was due, in part, to an assembly or workmanship defect in addition to manufacturing defects in the flanges. Higgins & Associates prepared a report on behalf of Travelers concluding that the flanges failed due to improper installation. Plastic Failure Labs prepared a report on behalf of the flange manufacturer concluding that the flanges failed due to improper installation by RK.”
At this point, Travelers denied coverage. RK sued alleging that the coverage for flange failure and water damage implicitly includes mitigation costs. The court rejected this claim, noting it would do so even if Travelers had paid for the replacement of the first two flanges. Nor did the court find that replacement of the faulty flanges is not "a covered cause of loss." RK also argued that as it was required to mitigate, Travelers was obligated to cover costs. However, the court found that “the mitigation costs expended by RK were not incurred in an effort to avoid damages from a potential breach of contract by Travelers.” The court additionally noted that despite RK’s claims, the Colorado courts have not found a common law duty to mitigate. Finally, the court found that the exclusions in the policy were not in violation of public policy.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
When an Insurer Proceeds as Subrogee, Defendants Should Not Assert Counterclaims Against the Insured/Subrogor
June 14, 2021 —
Gus Sara - The Subrogation StrategistIn a subrogation action, one party is substituted to the rights and remedies of another with respect to a lawful claim. The substituted party (the subrogee) is legally able to pursue any right or seek any remedy that would be available to the subrogor regarding that claim. But can a defendant in a subrogation action assert any claim against the subrogee that it would have against the subrogor? In Federated Mut. Inc. Co. v. Kosciusko County, No. 3:20-CV-960, 2021 U.S. Dist. Lexis 88735, the United States District Court for the Northern District of Indiana considered whether a defendant could assert counterclaims against the insureds/subrogors in an action filed in the name of their subrogee. The court held that since the insurerds/subrogors were not a party to the action and the defendant could assert the substance of its counterclaim as a defense, the defendant could not file counterclaims against the insureds/subrogors in the insurer’s subrogation action.
Kosciusko County arose from a motor vehicle accident involving a semi-tractor trailer owned by Bellman Oil Company, Inc. (Bellman) and B & B Transport, Inc. (B & B). The accident occurred on a highway in Kosciusko County in October of 2019. The accident caused the semi-tractor trailer containing ethanol fuel to roll over four times and burst into flames. Federated Mutual Insurance Company (FMIC) insured Bellman and B & B for the semi-tractor trailer and issued payments as a result of the accident.
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Travelers Insurance Sues Chicago for $26M in Damages to Willis Tower
May 15, 2023 —
Annemarie Mannion - Engineering News-RecordTravelers Property Casualty Co. is suing the City of Chicago and its water district for $26 million in damages caused when more than 1 million gallons of Chicago River water flooded into a 110-story skyscraper during a 2020 storm.
Reprinted courtesy of
Annemarie Mannion, Engineering News-Record
Ms. Mannion may be contacted at manniona@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Wildfire Insurance Coverage Series, Part 4: Coverage for Supply Chain Related Losses
July 18, 2022 —
Scott P. DeVries & Yosef Itkin - Hunton Insurance Recovery BlogBusiness loss is not limited to fire or smoke damage to its own property – it often arises from damage to the supply chain. In this post in the Blog’s Wildfire Insurance Coverage Series, we look at what coverage may exist when wildfire damages an entity’s supply chain.
In many instances, while the insured property does not sustain fire or smoke damage, wildfires can wreak havoc on the business supply chain. For some, contingent business interruption coverage may be a solution. Contingent business interruption insurance extends coverage for the loss of prospective earnings because of an interruption in the insured’s supply chain that is caused by damage to property that the insured neither owns nor operates.[1] Typically, the property covered is of a supplier or customer. For example, in 2000, Ericsson Telecom A.B., a mobile phone manufacturer, presented a substantial contingent business interruption claim based on a fire that damaged a Royal Philips Electronics semiconductor plant. Royal Philips supplied critical components for Ericsson’s mobile phones. The fire caused Royal Philips to close its plant, halting Ericsson’s phone production for six weeks, resulting in substantial losses.
Reprinted courtesy of
Scott P. DeVries, Hunton Andrews Kurth and
Yosef Itkin, Hunton Andrews Kurth
Mr. DeVries may be contacted at sdevries@HuntonAK.com
Mr. Itkin may be contacted at yitkin@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Colorado Construction Defect Action Reform: HB 17-1279 Approved by Colorado Legislature; Governor’s Approval Imminent
June 05, 2017 —
Erik G. Nielsen - Snell & Wilmer Legal AlertColorado developers frequently cite Colorado’s Construction Defect Action Reform Act (CDARA) as an obstacle to building new condominiums in the state. Developers contend that the law makes it too easy for condo boards to sue developers for workmanship issues, however trivial. As a result, Colorado has seen significant growth in the development of rental apartments, while development of new, for-sale, multi-unit housing, has declined in the state. In 10 years, new condo development in Colorado dropped from 20 percent to just 3 percent of total new-housing starts. Recognizing this issue, Governor Hickenlooper and the Colorado Legislature have taken an interest in reforming CDARA by, among other things, making it more difficult for condo boards and associations to sue construction professionals. Well on its way to becoming law, HB 17-1279 does exactly that.
After the enactment of HB 17-1279, the executive boards of homeowners’ associations (HOA) in common interest communities will have to satisfy three broad elements before bringing suit against a construction professional on behalf of the community’s individual unit owners.
Read the court decisionRead the full story...Reprinted courtesy of
Erik G. Nielsen, Snell & WilmerMr. Nielsen may be contacted at
egnielsen@swlaw.com
Ohio Supreme Court Rules That Wrongful Death Claims Are Subject to the Four-Year Statute of Repose for Medical Claims
January 16, 2024 —
Lewis Brisbois NewsroomCleveland, Ohio (January 2, 2024) - In a landmark 4-3 ruling, the Supreme Court of Ohio ruled on December 28 that wrongful death claims are subject to the four-year statute of repose contained in O.R.C. 2305.113(C) (“Medical Claim Statute of Repose”). Everhart v. Coshocton County Memorial Hospital, Slip No. 2023-Ohio-4670. Statutes of repose create an absolute bar to filing a lawsuit. When applicable, they bar plaintiffs from filing claims outside a specified time frame. The Medical Claim Statute of Repose creates a four-year window for commencing medical claims, which begins to run from “the occurrence of the act or omission constituting the alleged basis of the medical…claim.” O.R.C. 2305.113(C)(1). Medical claims commenced after the four-year period are barred.
The primary question before the Court was whether a wrongful death claim, which is separate and distinct from a medical negligence claim, can qualify as a “medical claim” within the context of the Medical Claim Statute of Repose. The Court answered in the affirmative. A wrongful death claim can qualify as a medical claim if the wrongful death claim “…arises out the medical diagnosis, care, or treatment, of any person.” O.R.C. 2305.113(E)(3). According to the majority, a wrongful death claim can fall within the broad definition of “medical claim” and, if it does, is subject to the Medical Claim Statute of Repose.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
California Contractors – You Should Know That Section 7141.5 May Be Your Golden Ticket
February 18, 2020 —
Amy L. Pierce, Mark A. Oertel & John Lubitz - Lewis Brisbois Bisgaard & Smith LLPUnder California’s Contractors’ State License Law, Cal. Bus. & Prof. Code §§ 7000 et seq., all contractors’ and subcontractors’ licenses expire two years from the last day of the month in which the license issued, or two years from the date on which the renewed license last expired. The Contractors State License Board (CSLB) sends licensees a renewal application 60 to 90 days prior to the date the license is set to expire.
Most contractors have various controls in place to make sure that the renewal application is timely filed and the required fee paid. Even so, we are only human and mistakes are made, and a renewal application filing deadline can be missed for a variety of reasons, e.g., the licensee’s mailing address has not been updated on the CSLB’s records, the individual responsible for filing the license renewal is out on leave, there has been a death in the family or a serious health issue, etc. Quoting Robert Burns, even “[t]he best-laid schemes of mice and men go oft awry” (To a Mouse, 1786).
General contractors should be cognizant of both their and their subcontractors’ license renewal obligations and deadlines.
If a licensee missed timely filing its renewal application, Business & Professions Code Section 7141.5may provide some relief. Section 7141.5 provides that the Registrar of Contractors,
“may grant the retroactive renewal of a license if the licensee requests the retroactive renewal in a petition to the registrar, files an application for renewal on a form prescribed by the registrar, and pays the appropriate renewal fee and delinquency fee prescribed by this chapter. This section shall only apply for a period not to exceed 90 days from the due date and only upon a showing by the contractor that the failure to renew was due to circumstances beyond the control of the licensee.”
Reprinted courtesy of Lewis Brisbois Bisgaard & Smith LLP attorneys
Amy Pierce,
Mark Oertel and
John Lubitz
Ms. Pierce may be contacted at Amy.Pierce@lewisbrisbois.com
Mr. Oertel may be contacted at Mark.Oertel@lewisbrisbois.com
Mr. Lubitz may be contacted at John.Lubitz@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of