Insurer Must Defend Claims of Alleged Willful Coal Removal
June 21, 2017 —
Tred R. Eyerly - Insurance Law HawaiiThe court found that the insured was entitled to a defense against claims for its alleged willful removal of coal from third parties' land. Liberty Mut. Fire Ins. Co. v. Bizzack Constr, 2017 U.S. Dist. LEXIS 70285 (W.D. Va. April 27, 2017).
The Virginia Department of Transportation (VDOT) contracted with Bizzack to perform work in widening U.S. Route 460. VDOT notified coal owners that it had been "necessary to remove certain coal" from their land during the construction of Route 460. Some of the coal owners sued Bizzack, seeking compensation for lost coal. They alleged Bizzack had illegally removed and sold their coal, and "damaged the remaining coal in place on the property."
Bizzack sought coverage from Liberty Mutual. Liberty Mutual filed suit seeking a declaration that it had no duty to defend or indemnify Bizzack. Cross-motions for summary judgment were filed. Liberty Mutual argued: (1) there was no "occurrence"; (2) exclusion j (5) applied; and (3) the "expected or intended injury" exclusion applied.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly - Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Builders Association Seeks to Cut Down Grassroots Green Building Program (Guest Post)
October 04, 2021 —
Christopher G. Hill - Construction Law MusingsFor this week’s year end Guest Post Friday here at Musings, we welcome Michael Anschel. Michael is the owner of Otogawa-Anschel Design-Build, a member of BATC, lead the development of and serves as a board member to MN GreenStar, the CEO of Verified Green, Inc., and writes the green blog for Remodeling Magazine Online.
If you have been following the sad state of affairs in Minnesota recently (no not the elections) you might be scratching a bald spot on your head in amazement. To my knowledge it is the only state in which the local builders association [ www.batconline.org ] has actually sued the local Green building program (MN GreenStar [ www.mngreenstar.org ]; going as far as filing a restraining order to keep them from certifying any new homes in the state.
This is, in my opinion, a tragic move in the wrong direction for everyone; builders and homeowners alike.
The builders group widely know for The Parade of Homes claims to have no interest in using the program or the brand MN GreenStar, so why seek to shut the program down? Even the lawyers have been scratching their heads trying to make sense of this bizarre and highly aggressive move. And things just get more bizarre from there.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Southern California Lost $8 Billion in Construction Wages
August 17, 2011 —
CDJ STAFFLos Angeles and Orange Counties are first on a list no area wants to be on. According to the Sacramento Bee, reporting on data from the U.S. Bureau of Economic Analysis, LA and Orange Counties saw an $8 billion drop in construction wages in 2010, as compared to 2006. In 2006, the region saw payrolls of $26.8 billion, but in 2010, that was reduced to $18.5 billion.
This was not the largest percentage change. Of the metropolitan areas with the largest declines in construction earnings, Las Vegas saw a $3.6 billion drop, however that represented half of their 2006 totals of $7.2 billion. Conversely, a $3.3 billion drop in the New York area represented only 10% of what had been $33.8 billion in payroll in 2006.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Failure to Meet Code Case Remanded to Lower Court for Attorney Fees
May 24, 2011 —
CDJ STAFFJudge Patricia J. Cottrell, ruling on the case Roger Wilkes, et al. v. Shaw Enterprises, LLC, in the Tennessee Court of Appeals, upheld the trial court’s conclusion that “the builder constructed the house in accordance with good building practices even though it was not in strict conformance with the building code.” However, Judge Cottrell directed the lower court to “award to Appellants reasonable attorneys' fees and costs incurred in their first appeal, as determined by the trial court.”
Judge Cottrell cited in her opinion the contract which specified that the house would be constructed “in accordance with good building practices.” However, after the Wilkes discovered water leakage, the inspections revealed that “that Shaw had not installed through-wall flashing and weep holes when the house was built.” The trial court concluded that:
“Separate and apart from the flashing and weep holes, the trial court concluded the Wilkeses were entitled to recover damages for the other defects they proved based on the cost of repair estimates introduced during the first and second trials, which the court adjusted for credibility reasons. Thus, the trial court recalculated the amount the Wilkeses were entitled to recover and concluded they were entitled to $17,721 for the value of repairs for defects in violation of good business practices, and an additional 15%, or $2,658.15, for management, overhead, and profit of a licensed contractor. This resulted in a judgment in the amount of $20,370.15. The trial court awarded the Wilkeses attorneys” fees through the Page 9 first trial in the amount of $5,094.78 and discretionary costs in the amount of $1,500. The total judgment following the second trial totaled $26,973.93.”
In this second appeal, Judge Cottrell concluded, that “the trial court thus did not have the authority to decide the Wilkeses were not entitled to their attorneys” fees and costs incurred in the first appeal.”
Read the court’s decision
Read the court decisionRead the full story...Reprinted courtesy of
Paul Tetzloff Elected As Newmeyer & Dillion Managing Partner
June 03, 2019 —
Newmeyer & Dillion LLPNewmeyer & Dillion LLP, a prominent business and real estate law firm, selected Paul Tetzloff as the firm's Managing Partner. His term began on January 1, 2019. A business litigator, Tetzloff will now oversee the firm's strategic plan and manage the firm's day-to-day business affairs.
"The Firm is incredibly fortunate to have Paul stepping into the role as Managing Partner. His energy, intelligence, leadership, and drive make him uniquely qualified to lead this Firm for years to come," said former Managing Partner Jeff Dennis. "I am excited to watch where the Firm is headed – we have such an amazing opportunity to continue to develop to even greater heights, and Paul will be a huge part of making that happen."
Active in his community, Tetzloff sits on the board for HomeAid Orange County and the Marine Raider Association.
Tetzloff is succeeding Dennis, who served in the role from 2012 to 2018. "Jeff was our managing partner for seven years and he did an outstanding job. We owe Jeff a debt of gratitude for his service," said Tetzloff of his predecessor. "I'm looking forward to continuing to build on the groundwork laid to help the firm reach new levels in the years to come."
Dennis' leadership allowed the firm to grow substantially under his tenure, including opening a Las Vegas, Nevada office and establishing thriving practice areas throughout various industries. Dennis will focus his energy on overseeing the firm's growing Privacy and Data Security practice.
Paul Tetzloff
paul.tetzloff@ndlf.com
Practice Areas
Business Litigation
Construction Litigation
Real Estate Litigation
About Newmeyer & Dillion
For almost 35 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, privacy & data security and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client's needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
What If an Irma-Like Hurricane Hit the New York City Metro Area?
September 20, 2017 —
Christopher Flavelle & Henry Goldman - BloombergIt sounds like a Hollywood disaster movie.
A Category 5 hurricane churning in the mid-Atlantic suddenly veers northwest -- and heads straight for New York City.
The good news is that, for now, experts agree a Cat 5-sized deluge appears to be a meteorological impossibility in the U.S. Northeast, given today’s sea temperatures and weather patterns.
The bad news: A storm doesn’t need to pack the wallop of a Harvey or an Irma to knock out the region. Superstorm Sandy, whose wind speed was a relatively tame 80 miles per hour when it reached New Jersey, did $70 billion of damage in October 2012. Irma made landfall in Puerto Rico at 185 mph.
Reprinted courtesy of
Christopher Flavelle, Bloomberg and
Henry Goldman, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Coronavirus Is Starting to Slow the Solar Energy Revolution
March 09, 2020 —
Bloomberg NewsThe coronavirus outbreak is threatening to slow the global solar-energy revolution as it cuts the supply of key equipment for solar and wind farms in China and beyond.
As cases of the disease mounted over the past week, manufacturers including Trina Solar Ltd. sounded the alarm over production delays while developers like Manila Electric Co. in the Philippines said projects would be held up.
“If the virus outbreak lasts beyond the first quarter and spreads to more geographies, as is currently happening in Korea and Italy, then it may very well slow down global renewable energy deployment,” said Ali Izadi-Najafabadi, head of analysis in Asia for BloombergNEF which has downgraded its outlook for installations this year.
Read the court decisionRead the full story...Reprinted courtesy of
Bloomberg