Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion
October 04, 2021 —
David Adelstein - Florida Construction Legal UpdatesSometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS.
Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:
The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
2022 Construction Outlook: Continuing Growth But at Slower Pace
January 24, 2022 —
Garret Murai - California Construction Law BlogIn the midst of a pandemic that has lasted far longer than I think many of us thought it would, it’s been a study in contrasts:
- There has been over 305 million COVID-19 cases and 5.5 million deaths worldwide since the start of the pandemic.
- The U.S. stock market gained a whopping 26.9% in 2021.
- The annual rate of inflation in the U.S. hit 6.8% in November 2021 the highest it has been in nearly 40 years.
- The U.S. unemployment rate stood at 4.2% at the end of 2021, down from 14.7% in April 2020, the second highest unemployment rate since the Great Depression.
- The Doomsday Clock struck 100 seconds before midnight in 2021 as scientists warn that global leaders are doing too little too late to combat climate change that has seen global temperatures rise roughly 2 degrees Fahrenheit since the pre-industrial era.
- 2021 saw the launch of the first all-civilian spaceflight by Elon Musk’s Space X which was just one of 16 private spaceflights by tech billionaires Richard Branson’s Virgin Galactic and Jeff Bezos’ Blue Origin.
For the construction industry, when we started out in 2021, economists were estimating that construction starts would be up just 4% in 2021 after taking a 14% free-fall in 2020. As it turned out, construction starts increased 12% in 2021. That’s why economic forecasts should be viewed less like a marksmanship competition and more like horseshoes and hand grenades. Close is about the best you can realistically hope for.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Making Construction Innovation Stick
February 22, 2018 —
Tom Sawyer, Jeff Rubenstone, and Scott Lewis – ENRIntegrating innovations into construction workflows—rather than serially testing, piloting and discarding them—is a definition of success. Yet few innovations—even ones that shine in trials—are absorbed into practice. Many just quietly go away, sending the work of vetting and testing them down the drain. That leaves some firms wondering if most construction technology innovation efforts are a waste of time.
Reprinted courtesy of Engineering News-Record authors
Tom Sawyer,
Jeff Rubenstone and
Scott Lewis
Mr. Sawyer may be contacted at sawyert@enr.com
Mr. Rubenstone may be contacted at rubenstonej@enr.com
Mr. Lewis may be contacted at lewisw@enr.com
Read the court decisionRead the full story...Reprinted courtesy of
Confidence Among U.S. Homebuilders Declines to Eight-Month Low
March 19, 2015 —
Bloomberg News(Bloomberg) -- Confidence among U.S. homebuilders unexpectedly fell in March to an eight-month low as prospective buyers were in little rush to shop for properties ahead of the busier spring selling season.
The National Association of Home Builders/Wells Fargo sentiment gauge dropped to 53 from 55 in February, figures from the Washington-based group showed Monday. The median forecast in a Bloomberg survey called for a gain to 56.
Sales of single-family homes declined to a five-month low and builder optimism about the outlook failed to improve, the report also showed. Low mortgage rates and job creation may help spur homebuyer interest in coming months.
Read the court decisionRead the full story...Reprinted courtesy of
Bloomberg NewsMichelle Jamrisko may be contacted at
mjamrisko@bloomberg.net
Building Group Has Successful 2012, Looks to 2013
February 14, 2013 —
CDJ STAFFThe North State Building Industry Association has looked back at 2012, and feels that they are “well-positioned to addressed future challenges in 2013 and beyond.” The organization, which represents home builders in Northern California, had several major accomplishments in 2012.
The NSBIA has managed to reduce fees that builders must pay. Due to their work with the Sacramento Regional County Sanitation District and the Sacramento Area Sewer District over the last several years, a new rate and fee methodology has been adopted, saving builders $3,000 per single family unit in SRCSD fees and $1,000 per acre in SASD fees. Fees were also reduced through agreements with the Folsom Cordova unified and Elk Grove school districts. The city of Rancho Cordova reduced its transportation fee by $3,500 per home.
In addition to their advocacy work, the NSBIA has continued its worker training programs. During 2012, 113 people participated in their Journeyman Upgrade classes, an increase of 20 from the prior year.
Read the court decisionRead the full story...Reprinted courtesy of
Traub Lieberman Partner Rina Clemens Selected as a 2023 Florida Super Lawyers® Rising Star
July 10, 2023 —
Rina Clemens - Traub LiebermanTraub Lieberman is pleased to announce that Rina Clemens of the Palm Beach Gardens office has been selected to the 2023 Florida Super Lawyers Rising Star list in the area of Personal Injury.
Super Lawyers, a Thomson Reuters business, is a rating service of lawyers from more than 70 practice areas, who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates, and peer reviews by practice area. Please
click here to learn more about the methodology for selection.
Read the court decisionRead the full story...Reprinted courtesy of
Rina Clemens, Traub LiebermanMs. Clemens may be contacted at
rclemens@tlsslaw.com
“Based On”… What Exactly? NJ Appellate Division Examines Phrase and Estops Insurer From Disclaiming Coverage for 20-Month Delay
August 20, 2019 —
Anthony L. Miscioscia and Timothy A. Carroll - White and Williams LLPOn May 28, 2019, the New Jersey Superior Court, Appellate Division examined the phrase “based on” in an assault-and-battery exclusion, finding that the phrase means “to make, form, or serve as the foundation of any claim, demand or suit.” C.M.S. Investment Ventures, Inc. v. American European Insurance Company, No. A-2056-17T3, 2019 N.J. Super. Unpub. LEXIS 1215, at *8-9 (N.J. Super. Ct. App. Div. May 28, 2019) (CMS). The CMS case is also notable because the Appellate Division held that a 20-month delay in disclaiming coverage was unreasonable and therefore warranted estoppel.
In CMS, the insured was allegedly warned by its tenant about a faulty ground-floor window that failed to lock properly. Afterward, an intruder broke into the tenant’s apartment and sexually assaulted the tenant, who sued the insured on a premises liability claim. Before she filed suit, the tenant sought payment from the insured’s CGL insurer directly. The insurer denied coverage based on the assault-and-battery exclusion and closed the file, but never informed the insured. Later, the tenant sued the insured, which sought a defense and indemnity from its insurer, which again denied coverage based on the exclusion. The insured then sought a declaration of coverage on grounds that the exclusion was ambiguous, and the insurer “was estopped from denying coverage, because it waited [20] months to inform CMS of its coverage decision.” The trial court ruled in the insured’s favor which led to the appeal in CMS.
Reprinted courtesy of
Timothy Carroll, White and Williams LLP and
Anthony Miscioscia, White and Williams LLP
Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com
Mr. Carroll may be contacted at carrollt@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
California Contractor License Bonds to Increase in 2016
December 02, 2015 —
Garret Murai – California Construction Law BlogThe post, which originally appeared on
The Surety Bond Insider, was written by Jon Gottschalk, a member of the SuretyBonds.com Educational Outreach team. on
SuretyBonds.com helps contractors fulfill their bonding requirements.
The Contractors State License Board (CSLB) is requiring all California contractors to purchase a $15,000 bond by January 1, 2016— a $2,500 increase from the $12,500 amount that was previously required. The additional $2,500 was previously accounted for by an additional requirement to obtain a contractor’s license. Those applying for the license had to post the $12,500 surety bond and proof of financial solvency in the amount of $2,500. Essentially, contractors were required to show that their current assets were greater than their liabilities by no less than $2,500. By increasing the bond amount to include that additional $2,500, the CSLB has removed the burden of proving financial solvency from those who wish to obtain their license.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com