COVID-19 Damages and Time Recovery: Contract Checklist and Analysis
April 27, 2020 —
Patrick J. Greene, Jr. - Peckar & AbramsonThis Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist.
Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool.
Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present:
a) complete or partial suspension of work,
b) additional work or requirements,
c) added cost,
d) delay, and
e) disruption.
Read the court decisionRead the full story...Reprinted courtesy of
Patrick J. Greene, Jr., Peckar & AbramsonMr. Greene may be contacted at
pgreene@pecklaw.com
What to do When the Worst Happens: Responding to a Cybersecurity Breach
November 21, 2018 —
Scott L. Satkin & J. Kyle Janecek – Newmeyer Dillion LLPCybersecurity is a growing concern for today's businesses. While it's always advisable to take whatever action possible to avoid a cybersecurity breach, no security measures can be one hundred percent perfect, and malicious actors are always innovating and trying to find new security flaws. The implementation of new technology brings with it new opportunities, but also potentially new vulnerabilities. And hackers have one major advantage – those working to defend against cyber-attacks have to try to find and fix every potential exploit, whereas those on the other side only need to find one. As demonstrated by recent high-profile breaches at Google and Facebook, even massive tech companies with access to vast financial resources and top engineering talent can still fall prey to cyber-attacks. Therefore, understanding how to respond to a breach is just as critical to a company's cybersecurity plan as attempting to prevent one. Below are a few solid tips on how to react when an organization's cybersecurity has been compromised.
Plan in Advance
The best response to a cybersecurity breach begins before the breach ever happens. A written incident response plan is of paramount importance. In the immediate aftermath of a cybersecurity breach, people will be scared and stressed. In those circumstances, they will be more likely to be able to respond effectively if there is a plan laid out for them and they have received training on how to follow that plan. Make sure that employees are trained on the parts of the plan that are relevant to them. Most may only need to know who to report to if they suspect a breach may have occurred, while those who will be involved in the breach response will need more in-depth training. The plan should also be updated regularly to account for staffing changes, new technology, and the evolving legal landscape. The law may also require a plan for responding to cybersecurity breaches, depending on the jurisdiction.
Call Your Lawyer- Early and Often
At the risk of sounding self-aggrandizing, attorneys are critical in responding to a cybersecurity breach. The most obvious reason is to advise clients on their legal obligations and potential liability – and this is indeed an important function. The patchwork of federal and state regulations governing cybersecurity is something laypeople – and even non-specialized attorneys – should navigate with caution. Of equal importance is the preservation of confidential communication under the attorney-client privilege. The presence of an attorney helps to improve the security of information surrounding the response to the breach because correspondence with that attorney is privileged, allowing candid evaluation of the breach. The ability to assert attorney-client privilege regarding an internal investigation and response can be quite useful in the event of a later external investigation or litigation.
To Disclose or Not to Disclose?
An important question that needs to be asked in the wake of a cybersecurity breach is whether the incident must be disclosed, and if so, when, how, and to whom should such disclosures be made? While many understandably wish that their mistakes and failures will never see the light of day, there are also many people who will want to know when a company's cybersecurity has been breached. Shareholders want to know – and may have a right to know – if such a breach has harmed the business. Consumers want to know if their personal information has been compromised so that they can protect against identity theft. Furthermore, state breach notification laws may mandate certain disclosures to consumers depending on facts surrounding the breach. Legal requirements from states, the federal government, and even foreign entities may also require companies to provide notices to one or more regulatory agencies.
An attorney can advise on whether a company is legally required to provide any notice in the aftermath of a data breach, but even though notice may not be a legal requirement in a particular set of circumstances, it may still be prudent to give it anyway. Google decided not to disclose the recent breach of data from its Google+ service to avoid a PR and regulatory backlash, but the fact that it had happened eventually leaked out anyway. Even though legal experts have opined in the aftermath that Google likely was not obligated to disclose the breach, the fact that it did not caused exactly what Google attempted to avoid, but with magnified effect. "Google Experiences Consumer Data Breach" may not have been a good headline, but "Google Hides Consumer Data Breach" was a worse one.
Remember: Protection Is Key
No company wants a cybersecurity breach, but past experience has increasingly demonstrated that this is not a question of "if" but rather one of "when" and "how bad." Planning ahead and knowing what to do when a data breach does happen can ensure that an organization bounces back from a breach as smoothly and painlessly as possible.
Scott Satkin and Kyle Janecek are associates in the Cybersecurity group of Newmeyer & Dillion. Focused on helping clients navigate the legal dispute implications of cybersecurity, they advise businesses on implementing and adopting proactive measures to prevent and neutralize cybersecurity threats. For questions on how they can help, contact Scott at scott.satkin@ndlf.com and Kyle at kyle.jancecek@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of cybersecurity, business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client's needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America© and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
General Contractor/Developer May Not Rely on the Homeowner Protection Act to Avoid a Waiver of Consequential Damages in an AIA Contract
August 04, 2011 —
Higgins, Hopkins, McLain & Roswell, LLCRecently, in Caribou Ridge Homes, LLC v. Zero Energy, LLC, et al., Case No. 10CV1094, Boulder County District Court Judge Ingrid S. Bakke entered a ruling and order on the Plaintiff’s Motion for Determination of Question of Law Pursuant to C.R.C.P. 56(h) on Issue of Damages. The Order found that the Plaintiff was not a homeowner intended to be protected by the Homeowner Protection Act (the “HPA”) and thus could not pursue its claims for consequential damages against Defendant.
By way of background, on June 18, 2008, Plaintiff Caribou Ridge Homes, LLC (“Caribou”) entered into a Standard Form Agreement Between Owner and Contractor AIA Document A114-2001 (the “Contract”) with Defendant Zero Energy, LLC (“Zero Energy”). Plaintiff hired Zero Energy to serve as a general contractor for the construction of a single-family home in the Caribou Ridge subdivision in Nederland, Colorado. A provision in the contract contained a mutual waiver of consequential damages (“Waiver”).
Read the full story…
Reprinted courtesy Higgins, Hopkins, McLain & Roswell, LLC
Read the court decisionRead the full story...Reprinted courtesy of
No Bad Faith In Filing Interpleader
August 19, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe Eighth Circuit determined that filing an interpleader action in the face of multiple claims against the policy holder did not constitute bad faith. Purscell v. Tico Ins. Co., 2015 U.S. App. LEXIS 10438 (8th Cir. June 22, 2015).
Ben Purscell's vehicle collided with another vehicle, in which Tim and Amy Carr were riding. The Carrs were injured, and Purscell's passenger, Amy Priesendorf, was killed. Before the accident, Priesendorf had stretched her leg over and put her foot on the accelerator, on top of Purscell's foot. As the other car approached, Purscell swerved to avoid an accident, but the two vehicles collided.
Purscell had a policy with Infinity Assurance Insurance Company. The policy limited liability to $25,000 per person and $50,000 per accident for bodily injury. Infinity put the full $50,000 per accident limits on reserve, with $25,000 designated to Priesendorf's fatality and $25,000 designated to the Carrs.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Do Hurricane-Prone Coastal States Need to Update their Building Codes?
April 15, 2015 —
Beverley BevenFlorez-CDJ STAFFProperty Casualty 360 reported that “a number of coastal states took no action to improve their building code systems since 2012, and a few have weaker systems in place, according to the Insurance Institute for Business & Home Safety (IBHS).”
The IBHS released their “Rating the States” report that published the results of their study of “the 18 most hurricane-prone states located along the Gulf of Mexico and the Atlantic Coast on their building regulations.” States can receive up to 100 points, with a higher score reflecting better state building requirements.
Delaware scored lowest with a mere 17 points—the same score it received in 2012. Virginia, the highest scored state, earned 95 points.
Read the court decisionRead the full story...Reprinted courtesy of
Include Contract Clauses for Protection Against Ever-Evolving Construction Challenges
May 30, 2022 —
Michael Henry & Kevin J. Riexinger - Construction ExecutiveThe first quarter of 2022 provided a valuable glimpse into some of the major issues the construction industry can expect to continue impacting jobsites for the rest of the year.
Early in the pandemic, construction was not immune from the shut-downs that swept across market sectors. Workers were staying home to shield themselves and their families from the COVID-19 virus (and variants). This caused delays with construction projects and failures to meet negotiated benchmarks or deadlines. Contractors were left to wonder whether they remained obligated to perform under their contracts, or whether COVID-19 allowed them to invoke force majeure clauses. Over the past two years, there has been much debate about whether force majeure clauses encompass COVID-19 risks.
Traditionally, force majeure is only invoked for significant weather events or natural disasters. Unsurprisingly, outcomes of legal actions regarding COVID-19 and force majeure varied by state and by contract. It didn’t take long for contractors to seek a more predictable and certain solution.
Reprinted courtesy of
Michael Henry & Kevin J. Riexinger, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Riexinger may be contacted at kriexinger@gllawgroup.com
Mr. Henry may be contacted at MbHenry@tcco.com
Read the court decisionRead the full story...Reprinted courtesy of
Skyline Bling: A $430 Million Hairpin Tower and Other Naked Bids for Tourism
January 21, 2015 —
Toluse Olorunnipa – BloombergAmerican cities are starting an architectural arms race to the sky with super-sized Ferris wheels, a 100-story observation tower and maybe even a mammoth golf ball atop a 300-foot tee planted in the Arizona desert.
From Phoenix to Camden, New Jersey, city officials and developers are seeking to punctuate their skylines with exclamation points, vying for the world’s attention with the next Eiffel Tower or London Eye.
Read the court decisionRead the full story...Reprinted courtesy of
Toluse Olorunnipa, BloombergMr. Olorunnipa may be contacted at
tolorunnipa@bloomberg.net
The Requirement to Post Collateral Under General Agreement of Indemnity Is Real
May 16, 2022 —
David Adelstein - Florida Construction Legal UpdatesIn prior postings, I have discussed the all-powerful General Agreement of Indemnity (click
here and
here). This is the document a bond-principal executes to obtain bonds (e.g., performance and payment bonds). Not only does the bond-principal execute this General Agreement of Indemnity, but typically, so do other indemnitors such as the company’s principals and their spouses, other related companies, etc. The objective is that the surety has financial comfort that if a claim is made against the bond, there are avenues where it will get reimbursed and indemnified for any cost it incurs, or payment it makes, relative to that claim against the bond. When a surety issues bonds, the objective is that all losses it incurs gets reimbursed because the bonds are NOT insurance policies.
One of the powerful tools the surety can exercise in the General Agreement of Indemnity is to demand the bond-principal and other indemnitors to post collateral in an amount the surety deems sufficient to cover any losses it may incur. This is a right in any General Agreement of Indemnity I have seen and is a right the surety can rightfully exercise.
A recent example is shown from the opinion in Philadelphia Indemnity Ins. Co. v. Quinco Electrical, Inc., 2022 WL 1230110 (M.D.Fla. 2022), which pertains to the surety’s motion for preliminary injunction.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com