Fairfield Connecticut Building Expert Directory

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Breach of an Oral Contract and Unjust Enrichment and Implied Covenant of Good Faith and Fair Dealing

December 23, 2023 — David Adelstein - Florida Construction Legal Updates
In an ideal world, parties would have written contracts. In reality, parties should endeavor to ensure every transaction they enter into is memorialized in a written contract. This should not be disputed. Of course, written contracts are not always the case. Parties enter transactions too often whereby the transaction is not memorialized in a clean written agreement. Rather, it is piecemealing invoices, or texts, or discussions, or proposals and the course of business. A contract can still exist in this context but it is likely an oral contract. Keep in mind if there is a dispute, what you think the oral contract says will invariably be different than what the other party believes the oral contract says. This “he said she said” scenario gets removed, for the most part, with a written contract that memorializes the written terms, conditions, and scope. A recent federal district court opinion dealt with the alleged breach of an oral contract. In Movie Prop Rentals LLC vs. The Kingdom of God Global Church, 2023 WL 8275922 (S.D.Fla. 2023), a dispute concerned the fabrication and installation of a complex, modular stage prop to be used for an event. But here lies the problem. The dispute was based on an oral contract and invoices. The plaintiff, the party that was fabricating the modular stage prop, sued the defendant, the party that ordered the stage prop for the event, for non-payment under various claims. The defendant countersued under various claims. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Quick Note: COVID-19 Claim – Proving Causation

August 03, 2020 — David Adelstein - Florida Construction Legal Updates
In certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk. No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Standard Lifetime Shingle Warranties Aren’t Forever

April 03, 2013 — CDJ STAFF
Olympia Construction’s roofing division explained to the web site Thurston Talk how long “lifetime” warranties on shingles really last. Your lifetime? You’re likely to live out the effective period of your lifetime shingle warranty. They note that 100% coverage of the shingle replacement typically lasts only for ten years (and does not cover removal of the existing defective shingles). After that, coverage continues to decline without covering any of the labor. And this can be significant, since they noted that they have seen cases in which a batch of defective shingles means that every home on the block has a defect claim. Read the court decision
Read the full story...
Reprinted courtesy of

New Standard Addresses Wind Turbine Construction Safety Requirements and Identifies Hazards

October 09, 2018 — Christopher Daniels - Construction Executive
American Society of Safety Professionals’ industry consensus standard, ANSI/ASSP A10.21 – 2018 Safety Requirements for Safe Construction and Demolition of Wind Generation/Turbine Facilities, is the first standard to identify and address hazards specific to wind turbine construction. It includes nearly a dozen appendices that provide additional consideration and guidance for hazards that vary between projects, turbines and geographical areas. The new A10.21 standard starts by requiring a site hazard identification prior to construction commencing. It establishes the general contractor as the responsible party for site hazard identification assessment. This is because the general contractor is usually one of the first entities on site able to assess the various challenges/concerns such as: geography, utilities, environmental, etc. This assessment is usually done by driving the project site and identifying GPS coordinates of specific challenges. Reprinted courtesy of Christopher Daniels, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Daniels may be contacted at chris.daniels@mortenson.com

What is Bad Faith?

April 04, 2022 — Stacy M. Manobianca - Saxe Doernberger & Vita, P.C.
As a policyholder, you may have heard the term “bad faith” in the context of litigation against your insurer. Bad faith in the insurance context is a catch-all term for a broad category of claims that can be brought against your insurer. Bad faith claims are common in insurance coverage litigation, and they can be a powerful tool in a policyholder’s arsenal. This post will serve as an introduction to some basic concepts surrounding bad faith litigation.

Bad Faith Defined:

Statutory vs. Common Law Bad Faith Claims
Breach of Contract vs. Tort Bad Faith Claims
Substantive vs. Procedural Bad Faith Claims

Best Practices Throughout the Claims Process:
Involve an Experienced Coverage Attorney
Conclusion

Read the court decision
Read the full story...
Reprinted courtesy of Stacy M. Manobianca, Saxe Doernberger & Vita, P.C.
Ms. Manobianca may be contacted at SManobianca@sdvlaw.com

BHA has a Nice Swing Donates to CDCCF

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates (BHA) would like to congratulate the winners of the BHA Has a Nice Swing golf game for charity. With the help of the participants, BHA was able to donate $1800 to the Construction Defect Community Charitable Foundation (CDCCF). CDCCF was established to provide financial assistance for active members of the construction defect community who have uninsured expenses because of a disability, sickness, and/or the death of a community member or their immediate family member. BHA would also like to congratulate their booth’s raffle winners. Prizes included an iPad Air, four sets of Dodger tickets, a Day at the Del Mar Races, and Best Buy gift cards. Read how the CDCCF assists the construction defect community... Read the court decision
Read the full story...
Reprinted courtesy of

Georgia Supreme Court Limits Damages Under Georgia Computer Systems Protection Act

March 01, 2017 — Chadd Reynolds – Autry, Hanrahan, Hall & Cook, LLP
On January 27, 2017, the Supreme Court of Georgia issued a decision determining whether the Georgia Computer Systems Protection Act (“GCSPA”) provides for punitive damages. While not directly related to construction, the GCSPA can be a potential mechanism for asserting claims against former employees that use company information stored in computers. Read the court decision
Read the full story...
Reprinted courtesy of Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Reynolds may be contacted at reynolds@ahclaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES