Seattle Washington Building Expert Directory

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The Firm Hits the 9 Year Mark!

July 22, 2019 — Christopher G. Hill - Construction Law Musings
It was 9 years ago today that I announced the formation and start of my solo practice, The Law Office of Christopher G. Hill, PC. Back then, my children were in elementary and middle school. Now I have two college students, one at Appalachian State University (with a budding photography talent that has provided some photos for this blog (including that on this post)) and the other at West Virginia University, and a rising high school junior. In just the past year I began a tenure on the Section Council Virginia Bar Association Construction and Public Contracts Law section and chair of its Legislative Committee where I assisted in the drafting of the change in the mechanic’s lien form that takes effect today.. I was named to both the Virginia Business Magazine Legal Elite in Construction Law and for a 3rd consecutive year to Virginia Super Lawyers in Construction Litigation. I spoke on how to deal with a DPOR complaint this past November at the 39th Annual Construction Law and Public Contracts seminar (one I highly recommend for any lawyer interested in construction). Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Delay Leads to Problems with Construction Defects

November 27, 2013 — CDJ STAFF
The Bardwells bought a new home in the Philadelphia area in 2000. Now, thirteen years later they’ve learned that their house has been slowly rotting away due to moisture trapped beneath the stucco. And they’re not alone. The O’Days bought a home for about $1 million, and it now needs about $200,000 in repairs. All the stucco has been removed and their home is being rebuilt. Monica Bardwell said that “everything was rotted,” and “there was not a piece of good wood to be salvaged.” Other area homeowners are finding similar problems. Wendy Meyer had her home inspected by Kevin Thompson. Mr. Thompson said, “I shouldn’t be able to take a piece of plywood like that and crush it in my hands completely disintegrated.” Mr. Thompson described it as due to “faulty construction,” which he estimated accounted for such damage “95 percent of the time.” The Pennsylvania Builders Association says that diligent homeowners can head off problems with maintenance. “Make sure water isn’t continually on the outside of the stucco,” said Brent Sailhamer of the PBA. “Make sure there are no large cracks where water can seep behind the stucco.” For those who bought their homes as far back as the Bardwells, it’s already too late to sue anyone. Pennsylvania construction defect law allows 12 years for lawsuits. Read the court decision
Read the full story...
Reprinted courtesy of

Human Eye Resolution Virtual Reality for AEC

July 02, 2018 — Aarni Heiskanen - AEC Business
Virtual reality opens new perspectives for communication and customer involvement in construction. Sweco, Varjo, and Teatime Research are together exploring the possibilities of VR using state-of-the-art technology. “I think that the use of VR in construction is still at a visionary stage and useful practical applications are rare,” says Niina Jaatinen, Service Manager at Sweco. “When we learned about Varjo’s exceptional technology, we thought that maybe it’s now time to start developing the really useful apps customers would yearn for.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

NY Estimating Consultant Settles $3.1M Government Project Fraud Case

November 23, 2020 — Eva Fedderly - Engineering News-Record
VJ Associates, a Hicksville, N.Y., estimating consultant, has agreed to pay $3.13 million in civil and criminal penalties to settle charges that the firm overbilled and falsified hours on multiple federal and state government-funded transportation and other contracts in New York and Massachusetts, the U.S. Attorney's office in Boston announced on Oct. 29. Reprinted courtesy of Eva Fedderly, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Alaska Supreme Court Finds Insurer Owes No Independent Duty to Injured Party

December 14, 2020 — Tred R. Eyerly - Insurance Law Hawaii
After the victim incurred injury inflicted by an insured party, the Alaska Supreme Court determined that the insurer owed no duty to the injured party. Martinez v. Government Employees Ins. Co., 2020 Alaska LEXIS 111 (Alaska Sept. 4, 2020). Joshua Martinez lost control of his truck and crashed into Charles Burnett's cabin. The cabin's heating fuel tank was damaged, and fuel drained onto the property and under the cabin. Burnett further alleged he suffered bodily injuries. Martinez was insured by GEICO under an auto policy. Two days after the accident, the state Department of Environmental Conservation (DEC) advised GEICO to hire a qualified environmental consultant and crew to clean up the fuel spill. Burnett told GEICO he wanted to do the cleanup himself and offered to do so for $25,000, the approximate amount of the consultant retained by GEICO. DEC did not consider Burnett qualified to handle the cleanup. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Conflicts of Laws, Deficiency Actions, and Statutes of Limitations – Oh My!

May 10, 2017 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
What law governs a deficiency action if the choice-of-law provisions in the note and deed of trust conflict? The Arizona Court of Appeals answered that very question in ZB, N.A. v. Hoeller, No. 1 CA-CV 16-0071 (Ct. App. April 15, 2017). It turns out, the note controls. The Facts In ZB, ZB, N.A. (ZB), a Utah bank, lent money to the Hoellers to purchase a commercial property in Missouri. The note included a choice-of-law provision stating that Utah law governed the debt. The deed of trust securing the commercial property, however, provided that Missouri law controlled “procedural matters related to the perfection and enforcement of [ZB’s] rights and remedies against the [p]roperty.” In 2012, the Hoellers defaulted, and the bank recovered the property through a trustee’s sale. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

Harmon Hotel Construction Defect Update

July 18, 2011 — CDJ STAFF

Coverage of the ongoing litigation concerning the Harmon Hotel continues to proliferate. Architectural Record and a number of other news outlets continue to provide additional details and coverage of the matter. Chief among the conditions alleged are improperly installed reinforcing steel inside link beams on 15 floors. MGM Claims that the conditions amount to hundreds of millions of dollars in damages, while Perini (the builder) indicated in a July 12th statement that the buildings problems are related to the design, and the they are “fixable.”

There is significant speculation that MGM Resorts International isn’t interested in repairing the hotel due to a glut of hotel rooms attendant to the troubled economy. In a statement Tuesday Perini reportedly stated that “Repairing and opening the Harmon would only create a greater glut of unused hotel rooms for MGM,” “If market conditions were better and MGM found that demand existed for the Harmon hotel rooms, MGM would not be claiming that the Harmon is unstable.”

MGM asserts that Perini failed to ”properly construct” the project. Clark County’s Department of Development Services has reportedly asked MGM to provide a plan to fix the project by August 15th.

The Harmon is part of the $8.5 billion CityCenter project that opened in the fourth quarter of 2009 and is jointly owned by MGM Resorts and Dubai World.

Prior reports indicated that the owner (MGM) had considered razing the entire project. The future of the project remains uncertain.

Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES