Fairfield Connecticut Building Expert Directory

Former Trump Atlantic City Casino Set for February Implosion

December 29, 2020 — Stephanie Loder - Engineering News-Record
The 39-story main tower of the former Trump Plaza hotel-casino on the Atlantic City, N.J., boardwalk, sold to investor Carl Icahn in 2016, will be imploded in February by a Philadelphia general contractor already in the process of dismantling the former showplace of President Donald Trump's real estate holdings. Reprinted courtesy of Stephanie Loder, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

When Do Hard-Nosed Negotiations Become Coercion? Or, When Should You Feel Unlucky?

October 21, 2019 — Stan Millan, Jones Walker, LLP - ConsensusDocs
Conflict in a negotiation is to be expected and is arguably healthy for the process. Owners and contractors are constantly engaged in negotiations; whether it be negotiating changes to the work, changes to the schedule, or changes to the contractual terms. But at what point does taking a strong position in a negotiation cross the line and become coercion or bad faith? A recent decision from the Armed Services Board of Contract Appeals touched on this very issue. While this is a government contract case, the issues discussed in this case (namely negotiating a change) are routinely encountered in just about every construction project. This decision is instructive because it adds to a trending line of cases that limit an owner’s and contractor’s negotiation tactics. On August 5, 2019, the board issued an opinion in the appeal of Sand Point Services, LLC vs. NASA, ASBCA Nos. 6189. In Sand Point Services, the contractor was hired by the owner to repair the Wallops Flight Facility’s aircraft parking apron. During its work, the contractor hit a differing site condition, namely unsuitable soils. The contractor sought additional time and money for this differing site condition. The owner ultimately responded with a show cause letter to the contractor claiming, among other breaches, that the contractor was significantly behind schedule. This was generally viewed by all parties as the start of default proceedings against the contractor. Read the court decision
Read the full story...
Reprinted courtesy of Stan Millan, Jones Walker, LLP
Mr. Millan may be contacted at smillan@joneswalker.com

Addressing Safety on the Construction Site

January 27, 2020 — Christopher G. Hill - Construction Law Musings
For this week’s Construction Law Musings Guest Post, we welcome a new face, Patrick Rafferty. Patrick (@ThePraff) is a consultant for Brahman Systems and has an interest in construction safety. First of all, I’d like to say that I am not an attorney. Anything I say in this article should be taken with a grain of salt. All of the information that I have written in this article comes from personal work experience on the worksite. Each year, construction sites around the nation see hundreds of thousands of injuries related to equipment operation and situations that could be avoidable with the right precautions in place. In 2011 alone, according to the Occupational Safety and Health Administration, there were 4,069 workers killed on a construction site, most of which were avoidable. Though some sort of on-site problems are unavoidable, they can be minimized with simple practices that every construction site should have in place, whether it is the building of a high-rise building or a simple house renovation. Here are some of the most common issues that lead to injuries on the construction site: Lack of training Before anyone steps onto a construction site, they need to have a thorough understanding of not only what they will be doing, but also how to use the equipment involved in the building process. All operators of heavy machinery should have verifiable training on the machine or equipment they will operate. Most equipment dealers offer training as part of their customer service, such as usage manuals, videos and quizzes. Once these are complete, many will offer a certificate of completion at the end of the process. The larger and more complex the machine, the more time should be allotted for training. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Another Worker Dies in Boston's Latest Construction Accident

June 20, 2022 — Scott Van Voorhis - Engineering News-Record
Boston Police and the US Occupational Safety and Health Administration are investigating a June 9 early morning construction accident that killed a worker in Boston’s Seaport district— the latest in a spate of fatalities at worksites across the city's metro area during the past 18 months. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Obama Says Keystone Decision May Be Announced in Weeks or Months

March 05, 2015 — Justin Sink – Bloomberg
(Bloomberg) -- President Barack Obama said a decision on whether to approve the Keystone XL pipeline is possible in weeks or months. The president told Reuters in an interview Monday that the decision definitely “will happen before the end of my administration.” Asked to be specific, he said, “Weeks or months.” Read the court decision
Read the full story...
Reprinted courtesy of Justin Sink, Bloomberg
Mr. Sink may be contacted at jsink1@bloomberg.net

First Circuit Rules Excess Insurer Must Provide Coverage for Fuel Spill

January 18, 2021 — Syed S. Ahmad & Adriana A. Perez - Hunton Andrews Kurth
The First Circuit recently held that a “Special Hazard and Fluids Limitation Endorsement” was ambiguous and therefore there was excess coverage for a fuel spill that occurred after a tanker-truck overturned. In Performance Trans. Inc. v. General Star Indem. Co., the First Circuit reversed the District Court’s grant of summary judgment in favor of General Star Indemnity Company. The District Court held that the excess policy General Star issued to Performance Trans. Inc. precluded coverage for a spill that resulted in the leaking of thousands of gallons of fuel. The District Court relied on the existence of a total pollution exclusion to bar coverage and held that the policy’s Special Hazards and Fluids Limitation Endorsement could not create an ambiguity that would afford coverage. Reprinted courtesy of Syed S. Ahmad, Hunton Andrews Kurth and Adriana A. Perez, Hunton Andrews Kurth Mr. Ahmad may be contacted at sahmad@HuntonAK.com Ms. Perez may be contacted at pereza@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Architect Not Responsible for Injuries to Guests

September 01, 2011 — CDJ STAFF

The Texas Court of Appeals has ruled, with one dissent, that the architectural firm that designed a home was not responsible to the injuries caused to guests when a balcony collapsed. Judge David Puryear wrote the majority opinion in Black + Vernooy Architects v. Smith.

Black + Vernooy designed a vacation home for Robert and Kathy Maxfield in 2000. The Maxfields hired a general contractor to build the home. The general contractor hired a subcontractor to build a balcony; however, the subcontractor did not follow the architect’s design in building the balcony.

A year after the house was completed; the Maxfields were visited by Lou Ann Smith and Karen Gravely. The balcony collapsed under the two women. Ms. Gravely suffered a broken finger, a crushed toe, and bruises. Ms. Smith was rendered a paraplegic as a result of the fall. They sued the Maxfields, the general contractor, and the architects for negligence. The Maxfields and the general contractor settled. A jury found that the architects held 10% of the responsibility. The architects appealed the judgment of the district court.

The Appeals Court reversed this judgment, noting that “there has been no allegation that the Architects negligently designed the balcony or that the Architects actually created the defects at issue.” Further, “the Smiths allege that the defect was caused by the construction practices of the contractor and subcontractor when the balcony was not built in accordance with the design plans of the Architects.”

The court found that even though the architects had a duty “to endeavor to guard against defects and deficiencies in the construction of the home and to generally ascertain whether the home was being built in compliance with the construction plans,” this duty did not extend to third parties.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES