SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Dog Ate My Exclusion! – Georgia Federal Court: No Reformation to Add Pollution Exclusion

September 28, 2017 — Philip M. Brown-Wilusz - Saxe Doernberger & Vita, P.C.
While schoolchildren know that the classic “the dog ate my homework” excuse doesn’t work, insurance companies are willing to try a variation of that excuse. Ace American Insurance Company (Ace), sold a property policy (the Policy) to Exide Technologies, Inc. (Exide). Exide sought coverage under the Policy for acid damage at its former battery factory. Ace denied coverage, citing to the pollution exclusion. The only problem? The Policy contained no pollution exclusion! Exide had procured policies from other insurers for several years prior to the inception of the Policy, all of which contained pollution exclusions. Exide instructed Marsh USA Inc. (Marsh), its broker, to procure insurance “on the same or better terms and conditions.” The resulting policy contained no pollution exclusion, and Exide sought coverage under the Policy for pollution-related losses. Read the court decision
Read the full story...
Reprinted courtesy of Philip M. Brown-Wilusz, Saxe Doernberger & Vita, P.C.
Mr. Brown-Wilusz may be contacted at pbw@sdvlaw.com

---

Want to Build Affordable Housing in the Heart of Paris? Make It Chic.

November 01, 2022 — Marie Patino & Kriston Capps - Bloomberg
The project at 12 Rue Jean-Bart is a modest one, just eight units of affordable housing on a narrow lot in Paris near the Luxembourg Gardens. The social housing project nevertheless caused a stir with neighbors in the 6th arrondissement, one of the city’s more affluent areas. When local politicians backing the project came to visit the building during its construction, neighbors shouted from windows across the street that it was a shame to build social housing here, according to Jean-Christophe Quinton, the Paris-based architect who designed the small in-fill development. Local resistance was a persistent feature of the project throughout its three-year-long construction, Quinton says; the building regularly faced harsh scrutiny in local newspaper Le Parisien. Reprinted courtesy of Marie Patino, Bloomberg and Kriston Capps, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

---

2018 Spending Plan Boosts Funding for Affordable Housing

April 11, 2018 — Emily Bias – Gravel2Gavel Construction & Real Estate Law Blog
On March 23, President Trump signed into law the Consolidated Appropriations Act, 2018, a $1.3 trillion spending package that includes a 12.5% increase in low-income housing tax credit allocations over the next four years, along with funding increases for several affordable housing programs. This is welcome news to affordable housing developers who have been facing funding gaps as a result of reductions in the corporate tax rate under the Tax Cuts and Jobs Act enacted in late 2017, which led to reduced pricing from equity investors. Read the court decision
Read the full story...
Reprinted courtesy of Emily Bias, Pillsbury Winthrop Shaw Pittman LLP
Ms. Bias may be contacted at emily.bias@pillsburylaw.com

---

Insurer's Motion to Dismiss Business Interruption, COVID-19 Claims Under Pollution Policy Fails

January 11, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The insurer was unsuccessful in seeking to dismiss business interruption claims due to COVID-19 under a pollution policy. New York Botanical Garden v. Allied World Assur., 2021 N.Y. Misc. LEXIS 6012 (N.Y. Sup. Ct. Oct.15, 2021). The insured was forced to cease operation after executive orders by the governor and mayor were issued in March 2020. The insured also had to reduce its in-person workforce by 100%. The insured's claim for business interruption and contingent business interruption were denied by Allied. The insured sued for a declaratory judgment. Allied moved to dismiss, arguing that the executive orders were issued for prophylactic reasons in an effort to mitigate the spread of the virus. They were not issued solely to address the presence of COVID-19 at any non-insured owned location, but were issued broadly to limit the risk of spreading the COVID-19 virus. The insured responded that its broader pollution liability policy was not a typical civil authority policy that required the physical loss or damage to property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Florida’s Supreme Court Resolves Conflicting Appellate Court Decisions on Concurrent Causation

December 21, 2016 — Afua S. Akoto – Saxe Doernberger & Vita, P.C.
The Supreme Court of Florida kicked off December with an opinion that determined which theory of recovery applies when multiple perils combine to create a loss, and at least one of those perils is excluded by the terms of a policy. In Sebo v. American Home Assurance Company, Inc.,1 the court resolved the conflict between the Florida Appellate Courts for the Second District and the Third District and declared the concurrent cause doctrine (CCD) as the more applicable theory of recovery over the efficient proximate cause doctrine (EPC). The underlying dispute concerned damage to a home Sebo purchased in Naples, Florida in April 2005. The American Home Assurance Company (AHAC) insured the home under a manuscript policy specifically created for the property with limits of over eight million dollars. In May 2005, Sebo discovered major water leaks in the main foyer, master bathroom, exercise room, piano room, and living room of the home. In August, paint fell off the walls after it rained, and it became clear that the house suffered from major design and construction defects. When Hurricane Wilma struck in October, the house was further damaged by rain water and high winds, and was eventually demolished. Read the court decision
Read the full story...
Reprinted courtesy of Afua S. Akoto, Saxe Doernberger & Vita, P.C.
Ms. Akoto may be contacted at asa@sdvlaw.com

---

Policy's Operation Classification Found Ambiguous

May 21, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Property damage caused by a subcontractor's sheet piling was found to be within the policy's operation classification, which included "grading of land." Canal Indemn. Co. v. Margaretville of NSM, Inc., No. 13-13541 (11th Cir. April 15, 2014). Canal issued a CGL policy to the insured. The policy had a classification limitation provision: “This insurance applies to bodily injury, property damage, personal injury, advertising injury or medical expense arising out of only those operations that are classified and shown on the Commercial General Liability Coverage Declarations . . .” The policy's Declarations, in turn, referred to the operation classification as "Grading of Land - INCL. Borrowing, Filling or Back Filling." The policy did not define these terms. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

California Mediation Confidentiality May Apply to Third Party “Participants” Retained to Provide Analysis

November 02, 2017 — Tony Carucci - Snell & Wilmer Real Estate Litigation Blog
California Evidence Code section 1119 governs the general admissibility of oral and written communications generated during the mediation process. Section 1119(a) provides that “[n]o evidence of anything said or any admission made for the purpose of, in the course of, or pursuant to, a mediation . . . is admissible or subject to discovery, and disclosure of the evidence shall not be compelled, in any . . . civil action . . . .” Cal. Evid. Code § 1119(a) (emphasis added). Similarly, section 1119(b) bars discovery or admission in evidence of any “writing . . . prepared for the purpose of, in the course of, or pursuant to, a mediation . . . .” Cal. Evid. Code § 1119(b) (emphasis added). Finally, section 1119(c) provides that “[a]ll communications, negotiations, or settlement discussions by and between participants in the course of a mediation . . . shall remain confidential.” Cal. Evid. Code § 1119(c) (emphasis added). Read the court decision
Read the full story...
Reprinted courtesy of Tony Carucci, Snell & Wilmer
Mr. Carucci may be contacted at acarucci@swlaw.com

---