De-escalating The Impact of Price Escalation
August 10, 2021 —
Brian C. Padove - ConsensusDocsWhat happens when construction material prices abruptly rise by 15%, 35%, 50%? Moreover, what happens to a construction project when such volatility occurs? While there is no definite answer, delays in procuring such materials and associated cost overruns will likely impact the construction project. The last 15 months contractors have had to work through extraordinary construction material price increases, such as a 90% price increase for lumber from April 2020 to April 2021. While there is no statistic quantifying the impact these increases have had on the construction industry, the increases surely have had an influence, whether it has been through lost profits, delays, or damage to contractors’ otherwise strong reputation for timely performance.
Considerations Prior To Contract Execution
The first way to mitigate price escalation is identifying materials most susceptible to price volatility during the bidding process and then having an open discussion with upstream parties regarding the potential price volatility. Additionally, the bid may also include either (1) an allowance for the materials providing additional funds, if necessary, should the material price increase, or (2) a shortened timeframe in which the bid is open, which would lessen the time in which a price shift may occur.
Read the court decisionRead the full story...Reprinted courtesy of
Brian C. Padove, Watt, Tieder, Hoffar & Fitzgerald, LLPMr. Padove may be contacted at
bpadove@watttieder.com
White and Williams Ranked in Top Tiers of "Best Law Firms"
November 08, 2021 —
White and Williams LLPWhite and Williams has achieved national recognition from U.S. News and World Report as a "Best Law Firm" in the practice areas of Insurance Law, Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law and Media Law. Our Boston, Delaware, New Jersey, New York City and Philadelphia offices have also been recognized in their respective metropolitan regions in several practice areas.
National Tier 1
Insurance Law
National Tier 2
Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law
National Tier 3
Media Law
Metropolitan Tier 1
Boston
Insurance Law
Litigation - Insurance
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams LLP
Will Claims By Contractors on Big Design-Build Projects Ever End?
February 27, 2023 —
Richard Korman - Engineering News-RecordIn the annals of construction disputes, it is a blip, not a blast.
After a Flatiron Construction-Zachry Group joint venture struck out on most of its arbitrated claims against engineering firm partners on the I-85/385 design-build interchange project in Greenville, S.C., and had others dismissed in court, the contractors had one more source from which to try to cover unexpected project costs: a contractor protective professional policy. Flatiron-Zachry filed a lawsuit last October in San Antonio federal court to try to force payment from Steadfast, a subsidiary of Zurich American Insurance Co.
Reprinted courtesy of
Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Court Rules on a Long List of Motions in Illinois National Insurance Co v Nordic PCL
May 10, 2012 —
CDJ STAFFThe case Illinois National Insurance Co. v Nordic PCL, et al. “involves a dispute about whether insurance benefits are available to a general contractor who built structures that allegedly have construction defects. Plaintiffs Illinois National Insurance Company (‘Illinois National’) and National Union Fire Insurance Company of Pittsburgh, PA (‘National Union’) (collectively, the ‘Insurers’), commenced this action for declaratory relief against Defendant Nordic PCL Construction, Inc., f/k/a Nordic Construction, Ltd. ("Nordic"), on August 23, 2011.”
The court was asked to rule on a long list of motions: “Counterclaim Defendants’ Request for Judicial Notice in Support of Their (1) Motion to Dismiss the Counterclaim and (2) Motion to Strike Portions of the Counterclaim, ECF No. 16 (‘Request for Judicial Notice’); Counterclaim Defendants’ Motion to Dismiss Counterclaim Filed October 24, 2011, ECF No. 14 (‘Motion to Dismiss Counterclaim’); Counterclaim Defendants’ Motion to Strike Portions of the Counterclaim Filed October 24, 2011, ECF No. 15 (‘Motion to Strike’); Third-Party Defendant Marsh USA, Inc.’s Motion to Dismiss or, in the Alternative, Stay Proceedings in Favor of Pending State Action, ECF No. 33 (‘Marsh’s Motion To Dismiss Or Stay’); Defendant and Third-Party Plaintiff Nordic PCL Construction, Inc., f/k/a Nordic Construction Ltd.’s Substantive Joinder to Third-Party Defendant Marsh USA Inc.’s Motion to Dismiss or, in the Alternative, Stay Proceedings in Favor of Pending State Action, ECF No. 36 (‘Nordic’s Joinder’); and Third-Party Defendant Marsh USA, Inc.’s Motion for Judgment on the Pleadings on Counts V and VI of Defendant/Third-Party Plaintiff Nordic PCL Construction, Inc.’s Third-Party Complaint, ECF No. 29 (‘Marsh’s Motion for Judgment on the Pleadings’).”
In result, the court reached the following decisions: “The court GRANTS IN RELEVANT PART the Insurers’ Request for Judicial Notice to the extent it covers matters relevant to these motions; GRANTS IN PART the Insurers’ Motion to Dismiss Counterclaim, but gives Nordic leave to amend the Counterclaim in certain respects; DENIES the Insurers’ Motion to Strike; DENIES Marsh’s Motion To Dismiss Or Stay and Nordic’s Joinder; and GRANTS Marsh’s Motion for Judgment on the Pleadings.”
The court provides a bit of background on the case: “This action arises out of alleged construction defects involving two projects on which Nordic acted as the general contractor. Nordic is a defendant in a pending state court action with respect to one of the projects and says it spent more than $400,000 on repairs with respect to the other project. Nordic tendered the defense of the pending state court action to the Insurers and sought reimbursement of the cost of repairs already performed. The Insurers responded by filing this action to determine their rights under the insurance policies issued to Nordic.”
Furthermore, the court presented a brief procedural history: “The Insurers commenced this declaratory action in this court on August 23, 2011. The Complaint asserts two claims, one seeking a declaration that the Insurers have no duty to provide a defense or indemnification regarding the Safeway Action, the other seeking such a declaration regarding the Moanalua Claims. Along with its Answer, Nordic filed a Counterclaim against the Insurers. The Counterclaim asserts breach of contract, breach of the covenant of good faith and fair dealing, misrepresentations and omissions of material fact, and bad faith, and seeks declaratory relief against the Insurers.”
The procedural history continues: “Nordic also filed a Third-Party Complaint against Marsh, the broker that had procured the Policies from the Insurers for Nordic. Nordic alleges that it reasonably believed that the Policies would provide completed operations insurance coverage for the types of construction defects alleged in the Safeway Action and Moanalua Claims. The Third-Party Complaint asserts breach of contract, negligence, promissory estoppel, breach of fiduciary duties, implied indemnity, and contribution and equitable subrogation.”
In conclusion, “The court GRANTS IN RELEVANT PART the Insurers’ Request for Judicial Notice. With regard to the Insurers’ Motion to Dismiss Counterclaim, the court GRANTS the motion as to Count I (breach of contract), Count II (duty of good faith and fair dealing), Count III (fraudulent and negligent misrepresentation), the portion of Count IV (bad faith) premised on fraud, and Count IV (declaratory relief). The court DENIES the motion as to Count IV (bad faith) that is not premised on fraud. Except with respect to the "occurrence" issue, which the court disposes of here on the merits, and Count V, which concerns only a form of relief, Nordic is given leave to amend its Counterclaim within three weeks of the date of this order. The court DENIES the Insurers’ Motion to Strike, DENIES Marsh’s Motion to Dismiss or Stay and Nordic’s Joinder, and GRANTS Marsh’s Motion for Judgment on the Pleadings with respect to Counts V and VI of the Third-Party Complaint.”
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Traub Lieberman Partner Colleen Hastie and Associate Jeffrey George Successfully Oppose Plaintiff’s Motion to Vacate Dismissal
September 11, 2023 —
Colleen E. Hastie & Jeffrey George - Traub LiebermanTraub Lieberman Partner Colleen Hastie and Associate Jeffrey George successfully opposed Plaintiff’s motion to vacate a prior dismissal of plaintiff’s medical malpractice action brought before the Supreme Court of the State of New York, Bronx County.
The lawsuit, commenced by Plaintiff in 2015, alleged medical malpractice stemming from treatment Plaintiff received at a New York medical facility after falling out of a window at a rental property owned by Traub Lieberman’s client (“Property Owner”). Property Owner moved to dismiss Plaintiff’s complaint or preclude Plaintiff from offering evidence in support of its claims, or in the alternative, compel plaintiff to produce all outstanding discovery. The Medical Facility cross-moved for the same relief. Defendants agreed to adjourn the motion until after plaintiff’s deposition, but plaintiff made no effort to secure an adjournment with the court and plaintiff filed no opposition to the motion, allowing the motion to be granted on default. Plaintiff waited nearly a year to file a motion to vacate the default judgment, despite receiving notification of the default from defense counsel. Property Owner, in opposing plaintiff’s motion, pointed to plaintiff’s long history of dilatory conduct and failure to comply with discovery orders in support of its position that plaintiff failed to show any good cause for its default on the motion to dismiss.
Reprinted courtesy of
Colleen E. Hastie, Traub Lieberman and
Jeffrey George, Traub Lieberman
Ms. Hastie may be contacted at chastie@tlsslaw.com
Mr. George may be contacted at jgeorge@tlsslaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Pre-Suit Settlement Offers and Construction Lien Actions
July 21, 2018 —
David Adelstein - Florida Construction Legal UpdatesIt is unfortunate, but in certain matters, a construction lien foreclosure action is not actually driven by the principal amount in dispute. Oh no. Rather, it is driven by attorney’s fees. That’s right. Attorney’s fees. This is true even though Florida applies the significant issues test to determine the prevailing party for purposes of attorney’s fees. However, oftentimes the prospect of attorney’s fees is enough for parties to fear that exposure.
There is a 1985 Florida Supreme Court case that I like to cite if applicable, C.U. Associates, Inc. v. R.B. Grove, Inc., 472 So.2d 1177, 1179 (Fla. 1985), that finds, “in order to be a prevailing party entitled to the award of attorney’s fees pursuant to section 713.29 [a construction lien claim], a litigant must have recovered an amount exceeding that which was earlier offered in settlement of the claim.” Accord Sullivan v. Galske, 917 So.2d 412 (Fla. 2d DCA 2006) (explaining that although contractor is receiving a judgment in his favor, he may not be the prevailing party if the homeowner offered to settle prior to the lawsuit for an amount equal to or greater than the award in the judgment).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Mexico Settles With Contractors for Canceled Airport Terminal
August 26, 2019 —
Eric Martin - BloombergMexico City's airport authority settled a dispute with builders on an 85 billion peso ($4.45 billion) contract for the terminal at a new Mexico City airport that President Andres Manuel Lopez Obrador canceled a month before taking office.
Grupo Aeroportuario Ciudad de la Mexico will pay 14.2 billion pesos, equivalent to 16.7% of the contract's total cost, to Constructora Terminal de Valle de Mexico, a consortium that includes Carlos Slim's Operadora Cicsa, the Communications and Transportation Ministry said in an emailed statement. The contracts represented 45% of the airport's total cost, the ministry said.
Read the court decisionRead the full story...Reprinted courtesy of
Eric Martin, Bloomberg
High Court Could Alter Point-Source Discharge Definition in Taking Clean-Water Case
March 18, 2019 —
Mary B. Powers - Engineering News-RecordThe U.S. Supreme Court's decision to review lower court rulings on whether a permit is required under the federal Clean Water Act when pollutants originate from a point source but are carried to navigable waters by a non-point source such as groundwater could set some new parameters for compliance, observers say.
Read the court decisionRead the full story...Reprinted courtesy of
Mary B. Powers, ENRENR may be contacted at
ENR.com@bnpmedia.com