Cambridge Massachusetts Building Expert Directory

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Governor Murphy Approves Legislation Implementing Public-Private Partnerships in New Jersey

August 28, 2018 — Steven M. Charney & Charles F. Kenny - Peckar & Abramson, P.C.
On Tuesday, August 14, 2018, New Jersey Governor Phil Murphy signed Senate Bill S-865, creating the state’s new Public-Private Partnership (PPP) law, making New Jersey the latest state to embrace this burgeoning delivery system for the construction of public infrastructure projects. The new law goes into effect 180 days from today. Peckar & Abramson (P&A) has teamed with both The Associated Construction Contractors of New Jersey (ACCNJ) and the Association for the Improvement of American Infrastructure (AIAI) who have been at the forefront in promoting this landmark legislation. P&A anticipates that the new law will create multiple opportunities for much needed public building and infrastructure projects in the state. In our recent Client Alert (June 29, 2018), we highlighted the numerous opportunities that will be available as a result of the PPP legislation, notably for the delivery of projects that may not have otherwise come to fruition. Reprinted courtesy of Steven M. Charney, Peckar & Abramson, P.C. and Charles F. Kenny, Peckar & Abramson, P.C. Mr. Charney may be contacted at scharney@pecklaw.com Mr. Kenny may be contacted at ckenny@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Right to Repair Act Isn’t Out for the Count, Yet. Homebuilders Fight Back

October 02, 2015 — Garret Murai – California Construction Law Blog
“[I]t ain’t how hard you hit; it’s about how hard you can get hit, and keep moving forward. How much you can take, and keep moving forward. That’s how winning is done. . . .” – Sylvester Stalone as Rocky Balboa in Rocky Balboa. Ding, ding. The Little Case That Roared Two years ago we wrote about a case that caused an uproar in the homebuilding industry – Liberty Mutual Insurance Company v. Brookfield Crystal Cove LLC, 219 Cal.App.4th 98 (2013) – in which the California Court of Appeals for the Fourth District held for the first time that the Right to Repair Act does not provide the exclusive remedy for construction defect claims involving “actual,” as opposed to “economic,” damages in new residential housing. It was a blow to the homebuilding industry who back in 2002, following a wave of construction defect lawsuits involving new residential housing, lobbied the State Legislature for the Right to Repair Act which gave homebuilders an opportunity to repair defects before being sued in court. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

L.A.’s Modest Solution to the ‘Missing Middle’ Housing Problem

May 24, 2021 — Kriston Capps - Bloomberg
Practical ideas aren’t often the stuff of architecture contests. Right off the bat, that set Los Angeles’s Low-Rise design challenge apart. A project led by the mayor’s office and the city’s chief design officer, Christopher Hawthorne, Low-Rise asked entrants to reimagine what an L.A. urban landscape with abundant housing could look like in the years to come. The organizers wanted the participating designers to think about their submissions the way they might approach a project for a local client or community. The results, which were unveiled this week, don’t look like future-forward science fiction, but rather doable local solutions to a thorny problem: the stubborn lack of affordable options across the city. Read the court decision
Read the full story...
Reprinted courtesy of Kriston Capps, Bloomberg

New York’s 2022 Comprehensive Insurance Disclosure Act: Significant Amendments to the C.P.L.R.

January 17, 2022 — Ellen H. Greiper & Kristen Carroll - Lewis Brisbois
New York, N.Y. (January 4, 2022) - On December 31, 2021, New York State Governor Hochul signed into law the Comprehensive Insurance Disclosure Act. The alleged justification for the act was to reduce the use of “delaying tactics” by compelling disclosure of the complete primary, excess, and umbrella policies implicated by the claim. These amendments will be unduly onerous on both carriers and defense counsel—for a multitude of reasons. It imposes an obligation on the insurer to immediately identify excess policies, eroding policies, and other information or contracts that affect the available coverage. Reprinted courtesy of Ellen H. Greiper, Lewis Brisbois and Kristen Carroll, Lewis Brisbois Ms. Greiper may be contacted at Ellen.Greiper@lewisbrisbois.com Ms. Carroll may be contacted at Kristen.Carroll@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

ENR Northwest’s Top Contractors Survey Reveals Regional Uptick

June 25, 2019 — Scott Judy - Engineering News-Record
A year ago, the 25 contractors responding to ENR Northwest’s Top Contractors survey collectively reported roughly $6.4 billion in 2017 revenue from the states of Washington, Oregon and Alaska. This year, the 27 contractors listed below—in alphabetical order—reported more than $8.8 billion in regional revenue for 2018. Read the court decision
Read the full story...
Reprinted courtesy of Scott Judy, ENR
Mr. Judy may be contacted at judys@enr.com

Massachusetts Couple Seek to Recuse Judge in Construction Defect Case

September 30, 2011 — CDJ STAFF

After seeing their $1 million jury award overturned on appeal by a judge who called the award “against the weight of evidence and likely due to misapprehension, confusion or passion,” Kathryn and Christian Culley are seeking to have him removed from the case. The Massachusetts Supreme Judicial Court has rejected their claim.

The Culleys claim that Judge Thomas R. Murtagh’s decision was influence by him membership in the Andover Country Club which is represented by the opposing counsel in their construction defect case. Justice Margot G. Botsford had denied the Culley’s request, ruling that they had other remedies available to them.

The SJC noted in their ruling that if the Culleys are alleging judicial misconduct a request must be made to the Commission on Judicial Conduct. Their lawyer plans to file a new motion for recusal with the SJC.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

2021 Executive Insights: Leaders in Construction Law

August 16, 2021 — Donald Berry - Construction Executive
Gregory Cokinos, President and CEO, Cokinos | Young First, experience in the construction industry is of primary importance and vital to successfully negotiating construction contracts and handling construction claims and disputes. Even a mildly complex construction dispute is more than most non-construction lawyers can properly handle. Issues concerning scheduling, productivity, change management and risk shifting (among many others) are complex and unique to construction and can be further complicated by the procedural and substantive law that differs from jurisdiction to jurisdiction. Second, it is essential that your law firm has a culture of representing construction professionals. Understanding construction nomenclature and how construction projects are staffed, organized and documented saves time and money in an already expensive and time-consuming process. You cannot overstate the advantage of shared resources within an established construction firm when evaluating and handling construction matters. A law firm that dedicates a significant portion of its practice to the construction industry is uniquely positioned to realize this advantage. Finally, as I tell our young lawyers, “success” only comes before “work” in the dictionary. Hard work is the key to successfully negotiating a contract or executing a litigation plan in this complex industry. So, look for a firm that is not afraid of working long days and weekends to achieve success. Reprinted courtesy of Donald Berry, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES