Alleging and Proving a Florida Deceptive and Unfair Trade Practices Act (FDUTPA) Claim
December 13, 2021 —
David Adelstein - Florida Construction Legal UpdatesWhen it comes to construction disputes, a Florida Deceptive and Unfair Trade Practices Act (known by its acronym “FDUTPA”) claim is not commonly asserted. A FDUTPA claim is a statutory claim under Florida Statute s. 501.201 en seq. This claim is NOT easy to prove, particularly in the construction context. Sometimes, a party will assert a FDUTPA claim to create a basis for attorney’s fees; however, that basis cuts BOTH ways, i.e., you can be liable for fees if you fail to prove the FDUTPA claim. In a construction dispute, a FDUTPA claim is one that really should be pled with caution after a party understands and fully considers what it MUST prove including the all-important consideration of how actual damages are determined under FDUTPA, which requires an actual loss. Nevertheless, it is good to know what you need to prove to support a FDUTPA claim in case you believe you have facts that can support a FDUTPA claim and actual damages under FDUTPA (known as benefit-of-the-bargain damages).
Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Pennsylvania Commonwealth Court Holds that Nearly All Project Labor Agreements are Illegal
February 18, 2019 —
Wally Zimolong - Supplemental ConditionsIn what is nothing short of a monumental decision, on January 11, 2019, the Pennsylvania Commonwealth Court in Allan Myers L.P. v. Department of Transportation ruled that nearly all project labor agreements in Pennsylvania are illegal under the Commonwealth’s procurement code.
What are Project Labor Agreements?
In short, Project Labor Agreements (PLAs) are pre-hire agreements that set the working conditions for all employees of contractors working on a construction project. Typically, a PLA is entered into between an public or private construction project owner and certain local building trade unions. PLAs require the use of union labor that is to be hired exclusively through the hiring halls of the unions who are parties to the PLA. PLAs are controversial because, among other reasons, while not expressly excluding non-union contractors from performing work on the project, they require non-union firms to use union members instead of their regular employees.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
Defining Constructive Acceleration
March 22, 2021 —
David Adelstein - Florida Construction Legal UpdatesWhen it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim.
In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Insurer’s Broad Duty to Defend in Oregon, and the Recent Ruling in State of Oregon v. Pacific Indemnity Company
January 02, 2024 —
Keith Sparks - Ahlers Cressman & Sleight PLLCOregon law mandates a broad duty to defend, requiring insurers to provide legal representation to their policyholders whenever there is a potential for coverage under the policy. The significance of this broad interpretation means that an insurer has a duty to defend an insured even in situations where the alleged facts only imply a covered claim, and even in situations where the underlying claim is ultimately not covered by the policy. The insurer’s duty to defend is triggered if the allegations of the complaint, reasonably interpreted, could result in the insured being held liable for damages covered by the policy. This is referred to as the “four-corners” rule; it is also sometimes referred to as the eight-corners rule (for the four corners of the complaint plus the four corners of the policy). Oregon’s adoption of a broad interpretation of the duty to defend affirmatively places the onus on insurers to err on the side of coverage.
This broad duty to defend is based on the principle that an insured should not have to bear the expense of defending a lawsuit that the insurer may ultimately have to pay for. The duty to defend is also important because it helps ensure that insureds have access to legal representation when faced with a lawsuit.
Read the court decisionRead the full story...Reprinted courtesy of
Keith Sparks, Ahlers Cressman & Sleight PLLCMr. Sparks may be contacted at
keith.sparks@acslawyers.com
Attorney Writing Series on Misconceptions over Construction Defects
June 28, 2013 —
CDJ STAFFMark Wiechnik, a litigation partner at Herrick, Feinstein LLP, has started a seven-part series in which he looks at the misconceptions homeowner board members have when they’re facing construction defect lawsuits. He opens by setting the scene of unit owners “complaining of leaks, roof problems, mold and myriad of other issues”, but conflicting views on what to do about them. In his series, he looks at some of the most common mistaken assumptions and discusses how board members should respond.
Wiechnik’s first misconception examined is the claim that “we should file a homeowners warranty claim right away!” He notes that this is “rarely a good idea,” since if the building is more than two years old, the warranty will only be worthwhile if the building is near collapse. He also notes that once you file a warranty claim, “the association is precluded from ever filing a lawsuit on that issue.”
Additionally, Wiechnik points out that filing a warranty claim puts everything into the hands of an arbitrator, who gets control of the whole process and whose decision is final, whether the association is happy with the results. Further, he notes, “the program favors builders and contractors over the homeowners.”
In his second section, he looks at the fears that if the developer is bankrupt, there is no point is suing. Here he notes that the money for repairs does not come from the developer, but “from the developer’s and subcontractor’s insurance carriers.”
Read the court decisionRead the full story...Reprinted courtesy of
Finding of No Coverage Overturned Due to Lack of Actual Policy
March 18, 2019 —
Tred R. Eyerly - Insurance Law HawaiiThe Appellate Division overturned a verdict for the insurer when the actual policy was never introduced at trial. Pennsylvania Lumbermens Mut. Ins. Co. v. B&F Land Dev. Corp., 2019 N.Y. App. Div. LEXIS 264 (N.Y. App. Div. Jan 16, 2018).
The decedent was killed when he fell through a skylight while working on a premises owned by B&F Land Development Corporation. The estate sued B&F for wrongful death.
B&F tendered to its carrier, Pennsylvania Lumbermens Mutual (PLM). PLM issued a reservations of rights. It later denied coverage because the location of the loss was not a location listed on the policy, an exclusion barred coverage for bodily injury arising out of B&F's ongoing operations conducted by it or on its behalf, and the loss was not reported to PLM as soon as practicable.
PLM sued B&F and the estate for a declaratory judgment that it had no duty to defend or indemnify. A default judgment was entered against B&F after it failed to answer. Trial proceeded against the estate
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Standard of Care
December 16, 2019 —
Jay Gregory - Gordon & Rees Construction Law BlogOne of the key concepts at the heart of Board complaints and civil claims against a design professional is whether or not that design professional complied with the applicable standard of care. In order to prevail on such a claim, the claimant must establish (typically with the aid of expert testimony) that the design professional deviated from the standard of care. On the other side of the coin, to defend a design professional against a professional malpractice claim, defense counsel attempts to establish that – contrary to the claimant’s allegations – the design professional, in fact, complied with the standard of care. Obviously, it becomes very important in such a claim situation to determine what the standard of care is that applies to the conduct of the defendant design professional. Often, this is easier said than done. There is no dictionary definition or handy guidebook that identifies the precise standard of care that applies in any given situation. The “standard of care” is a concept and, as such, is flexible and open to interpretation. Traditionally, the standard of care is expressed as being that level of service or competence generally employed by average or prudent practitioners under the same or similar circumstances at the same time and in the same locale. In other words, to meet the standard of care a design professional must generally follow the pack; he or she need not be perfect, exemplary, outstanding, or even superior – it is sufficient merely for the designer to do that which a reasonably prudent practitioner would do under similar circumstances. The negative or reverse definition also applies, to meet the standard of care, a practitioner must refrain from doing what a reasonably prudent practitioner would have refrained from doing.
Although we have this ready definition of the standard of care, in any given dispute it is practically inevitable that the parties will have markedly different opinions as to: (1) what the standard of care required of the designer; and (2) whether the defendant design professional complied with that requirement. The claimant bringing a claim against a design professional typically will be able to find an expert reasonably qualified (at least on paper) who will offer an opinion that the defendant failed to comply with the standard of care. It is just as likely that the counsel for the defendant design professional will be able to find his or her own expert who will counter the opinion of the claimant’s expert and maintain that the defendant design professional, in fact, complied with the standard of care. What’s a jury to think?
The concept of standard of care is intertwined with the legal concept of negligence. In the vast majority of law suits against design professionals, a claimant (known as the plaintiff) will assert a claim for negligence against the design professional now known as the defendant.1 As every first year law student learns while studying the field of “Torts,” negligence has four subparts. In order for a defendant to be found negligent, the claimant must establish four elements: (1) duty; (2) breach; (3) causation; and (4) damages. In other words, to establish a claim against a defendant design professional, a plaintiff must demonstrate that the defendant owed the plaintiff a duty of care but breached that duty and, as a result, caused the plaintiff to suffer damages.
Read the court decisionRead the full story...Reprinted courtesy of
Jay Gregory, Gordon & Rees Scully MansukhaniMr. Gregory may be contacted at
jgregory@grsm.com
Return-to-Workplace Checklist: Considerations and Emerging Best Practices for Employers
July 20, 2020 —
Nancy Conrad & George C. Morrison - White and Williams LLPAs employers plan to return employees to the workplace, they should proceed with careful planning and incorporate best practices and measures to assure a safe, responsible and productive workplace. While there is no "one size fits all" plan, the following checklist will assist in assuring that your work environment includes the key safety components to return to the workplace in the midst of a pandemic.
PREPARING THE WORKPLACE FOR RETURN & GENERAL HEALTH AND SAFETY
- Create a company task force, safety committee or coordinator to oversee implementation of policies that address and enforce practices related to COVID-19.
- Ensure HVAC systems are functional, have been properly cleaned and serviced and tuned to maximize airflow and filtration.
- Review and increase cleaning protocols in coordination with lease terms and cleaning contracts. Ensure regular and thorough office cleanings, with a focus on high-touch surfaces and areas. Document cleaning protocols and schedule.
- Implement social distancing requirements and provide visual markers on floors in compliance with applicable federal, state and local orders.
- Rearrange work spaces, conference rooms and lunchrooms to comply with social distancing requirements.
- Post notices about the number of individuals permitted in elevators, stairwells, rooms and on the premises.
- Restrict movement between departments and floors.
Reprinted courtesy of
Nancy Conrad, White and Williams LLP and
George C. Morrison, White and Williams LLP
Ms. Conrad may be contacted at conradn@whiteandwilliams.com
Mr. Morrison may be contacted at morrisong@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of