Seattle Washington Building Expert Directory

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Flood Policy Does Not Cover Debris Removal from Property

May 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Third Circuit affirmed the granting summary judgment to the insurer over a dispute as to debris removal under a Standard Flood Insurance Policy (SFIP). Torre v. Liberty Mut. Fire Ins. Co., 2015 U.S. App. LEXIS 4902 (3rd Cir. March 26, 2015). The Torres' property sustained substantial damage from Hurricane Sandy. Claims for flood damage were submitted to Liberty. Liberty paid a total of $235,751.68, which included the cost of removing debris from the house. An additional $15,520 for the cost of removing sand and other debris deposited on their land in front of and behind the Torres' home was denied on the grounds that the SFIP did not cover such removal. The Torres filed suit and cross-motions for summary judgment were filed. The district court denied the Torres' motion and granted Liberty's motion. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insured's Jury Verdict Reversed After Improper Trial Tactics

October 09, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The appellate court reversed a jury verdict for the insured due to improper trial tactics by his attorney. Homeowners Choice Property and Cas. Ins. Co., Inc. v. Kuwas, 2018 Fla. Ct. App. LEXIS 9500 (Fla. Ct. App. July 5, 2018). The insured sued Homeowners Choice (HCI) alleging breach of contract due to a denial of coverage for property damage as a result of water loss. During the trial, HCI raised objections to various questions posed by the insured's counsel during the testimony of HCI's litigation manager, as well as various closing arguments made by the insured. The jury entered a verdict for the insured for a substantial sum. HCI appealed. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Court Holds That Parent Corporation Lacks Standing to Sue Subsidiary’s Insurers for Declaratory Relief

May 12, 2016 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In D. Cummins Corp. v. U.S. Fidelity & Guaranty (no. A142985, filed 3/30/16), a California Court of Appeal upheld the dismissal of a declaratory relief action filed by the parent holding company of an insured corporation seeking coverage for asbestos claims. Cummings Corp. installed asbestos containing products in California. It had been insured by USF&G between 1969 and 1992. Cummings Holding, LLC was the parent and majority shareholder of Cummings Corp., which had no assets. The holding company claimed to be “the sole entity responsible for managing the affairs of Cummins Corp., including making decisions as to litigation strategy, resolution and settlement,” and sued USF&G seeking a declaratory judgment that the insurer was obligated to defend and/or indemnify Cummins Corp., “in full, including, without limitation, payment of the cost of investigation, defense, settlement and judgment . . . , for past, present and future Asbestos Suits.” The insurer demurred on the ground that the holding company had insufficient interest in its insurance policies and, consequently, lacked standing to sue for declaratory relief. Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Read the court decision
Read the full story...
Reprinted courtesy of

Wendel Rosen’s Construction Practice Group Receives “Tier 1” Ranking by U.S. News and World Reports

November 10, 2016 — Garret Murai – California Construction Law Blog
Wendel Rosen’s Construction Practice Group has received a “Tier 1” ranking by U.S. News and World Reports in its 2017 Best Law Firms rankings and the firm as a whole has been named one of the “Best Law Firms.” This is the fourth consecutive year that Wendel Rosen’s Construction Practice Group has achieved a “Tier 1” ranking. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Hawaii Supreme Court Finds Excess Can Sue Primary for Equitable Subrogation

October 21, 2015 — Tred R. Eyerly – Insurance Law Hawaii
In responding to a certified question from the U.S. Distric Court, the Hawaii Supreme Court determined that an excess carrier can sue the primary carrier for failure to settle a claim in bad faith within primary limits. St. Paul Fire & Marine Ins. Co. v. Liberty Mut. Ins. Co., 2015 Haw. LEXIS 142 (Haw. June 29, 2015). St. Paul, the excess carrier, and Liberty Mutual, the primary carrier, issued polices to Pleasant Travel Service, Inc. The primary policy covered up to $1 million. Pleasant Travel was sued for damages resulting from an accidental death. St. Paul alleged that Liberty Mutual rejected multiple pretrial settlement offers within the $1 million primary policy limit. A trial resulted in a verdict of $4.1 million against Pleasant Travel. The action settled for a confidential amount in excess of the Liberty Mutual policy limit. St. Paul paid the amount in excess. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Government’s Termination of Contractor for Default for Failure-To-Make Progress

July 10, 2023 — David Adelstein - Florida Construction Legal Updates
Whenever you elect to terminate the other party for cause or for default, you need to JUSTIFY the basis of the cause or default. The reason being is that a termination for default or cause is the harshest contractual remedy. This is why the other party will typically either (i) convert the termination for default into one for convenience, or (ii) if there is no termination for convenience provision in the contract, argue the terminating party breached the contract by terminating the contract without rightful justification. The key is if you are going to terminate a party for cause of default, make sure you have memorialized the persuasive reasons for exercising the termination, and can otherwise reasonably support the justification. Do not, and I repeat, do not haphazardly exercise a termination for default and think you do not have to justify the basis for the termination. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

It’s Too Late, Lloyd’s: New York Federal Court Finds Insurer Waived Late Notice Defense

June 05, 2023 — Latosha M. Ellis & Janine A. Hanrahan - Hunton Insurance Recovery Blog
A New York federal judge recently ruled that an insurer waived its late notice defense because a generic reservation of rights was insufficient to preserve it. As a result, the policyholder’s claim was preserved despite being submitted more than three months after the loss—a delay which would ordinarily be fatal under New York law. The decision underscores the importance both of timely submission of claims and careful attention to reservation of rights letters. Background Mave Hotel Investors LLC (“Mave”) owns a small hotel in Manhattan that was insured by Certain Underwriters at Lloyd’s, London (“Lloyd’s”). From October 2017 to October 2020, Mave contracted with a housing network to temporarily house homeless families and their children in the hotel. When the contract with the housing network terminated in October 2020, Mave alleged that the rooms were severely damaged and that it had to pay $1.4 million to repair them. Reprinted courtesy of Latosha M. Ellis, Hunton Andrews Kurth and Janine A. Hanrahan, Hunton Andrews Kurth Ms. Ellis may be contacted at lellis@HuntonAK.com Ms. Hanrahan may be contacted at jhanrahan@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES