Columbus Ohio Building Expert Directory

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Injured Subcontractor Employee Asserts Premise Liability Claim Against General Contractor

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
In an interesting opinion, an injured employee of an electrical subcontractor sued the general contractor of a parking garage project under a premise liability theory after being injured when stepping on an uncovered floor drain at the project site. There is no discussion in the opinion as to workers compensation immunity. Rather, the discussion centers on the injured employee’s premise liability claim as to whether the general contractor “breached its duty to maintain the premises in a reasonably safe condition by leaving the drain uncovered and failing to warn of the danger of the uncovered drain.” Pratus v. Marzucco’s Construction & Coatings, Inc., 46 Fla.L.Weekly D186a (Fla. 2d DCA 2021) The trial court granted summary judgment in favor of the general contractor finding that the drain was open and obvious on the site. The Second District Court of Appeal reversed the summary judgment with a discussion as to premise liability claims, particularly as it pertains to a business invitee, which is what the injured employee of the electrical subcontractor was. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Former Sponsor of the Lenox Facing Suit in Supreme Court

January 13, 2014 — Melissa Zaya-CDJ STAFF
Lewis Futterman, former sponsor of the Lenox condominium in Harlem, New York, is being sued by the condo board for alleged “building code violations, construction defects, and fraud” according to New York Curbed. The residents claim that Futterman filed for bankruptcy in 2010 to avoid paying for repairs. The Lenox condo board filed suit in the New York Supreme Court last December 31st. The Lenox’s condo board claims that the building has “fundamental structural flaws, a defective roof and pervasive leakage,” reports Rowley Amato of New York Curbed. The board also claims the original offering plans were not the same as the units purchased by residents in 2006. Residents paid an estimated two hundred and sixty thousand to repair defects within the condominium, and they are pursuing a minimum of four million in damages. Katherine Clarke of The Real Deal stated that Futterman would only “say that the issue was between the residents and the construction company which built the project.” Read the full story at New York Curbed... Read the full story at The Real Deal... Read the court decision
Read the full story...
Reprinted courtesy of

Recent Opinions Clarify Enforceability of Pay-if-Paid Provisions in Construction Contracts

May 29, 2023 — Patrick McKnight - The Dispute Resolver
Several recent opinions and legislative actions have brought the controversial nature of pay-if-paid provisions into focus in early 2023. Pay-if-paid provisions are contractual mechanisms designed to shift the risk of non-payment from General Contractors to lower-tier subcontractors. In other words, pay-if-paid provisions generally do not require payment to downstream subs until after the GC or Prime are themselves paid in-full by the owner. Recent developments reflect the differing approaches taken by courts when addressing pay-if-paid provisions, ranging broadly from prohibition to full enforceability. Other jurisdictions fall somewhere in the middle, viewing such provisions with varying amounts of skepticism on the grounds heir impact on smaller downstream subs is disproportionate and unfair. Pay-if-paid provisions are often contrasted against “pay-when-paid” provisions. Pay-when-paid provisions may require payment within a specified duration but remove the upstream contractor’s payment in-full as a condition precedent. The brief discussion below will not explore pay-when-paid, no damage for delay provisions, or statutory prompt payment acts. Instead, this article serves as a primer on recent legal developments related to pay-if-paid provisions exclusively. Read the court decision
Read the full story...
Reprinted courtesy of Patrick McKnight, Fox Rothschild LLP
Mr. McKnight may be contacted at pmcknight@foxrothschild.com

Pollution Exclusion Bars Coverage for Inverse Condemnation Action

June 02, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The South Carolina Court of Appeals found there was no coverage for an inverse condemnation action based upon the policy's pollution exclusion. South Carolina Ins. Reserve Fund v. E. Richland County Public Service District, 2016 S. C. App. LEXIS 32 (S.C. Ct. App. March 23, 2016). In 2010, Coley Brown filed a complaint against the East Richland County Public Service District ("District") for inverse condemnation, trespass, and negligence. The complaint alleged that the District had installed a sewage force main line and an air relief valve on Brown's street, and the valve released offensive odors on his property many times a day. The stench caused Brown to buy a new piece of property and move, but he was unable to sell the old property. The district tendered the complaint to the South Carolina Insurance Reserve Fund ("Fund"), but coverage was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

City Covered From Lawsuits Filed After Hurricane-Damaged Dwellings Demolished

January 15, 2014 — Tred R. Eyerly - Insurance Law Hawaii
The Fifth Circuit affirmed the District Court's finding that a duty to defend was owed St. Bernard Parish after it was sued for condemning and demolishing housing destroyed by Hurricane Katrina. Lexington Ins. Co. v. St. Bernard Parish Gov't, 2013 U.S. App. LEXIS 24292 (5th Cir. Dec. 6, 2013). St. Bernard's policies with Lexington provided coverage for "property damage" and "personal and advertising injury." The policies included a $10,000,000 per occurrence and aggregate limit, subject to a $250,000 retained limit. Lexington denied coverage and filed for a declaratory judgment that the policies' $250,000 retained limit applied separately to each alleged demolition or property damage asserted in the underlying actions. Under this theory, no defense would be owed because no property had a value exceeding $250,000. The District Court found that only one retained limit applied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Property Insurance Exclusion for Constant or Repeated Leakage of Water

March 14, 2018 — David Adelstein – Florida Construction Legal Updates
A property insurance policy, no different than any insurance policy, contains exclusions for events that are NOT covered under the terms of the policy. One such common exclusion in a property insurance policy is an exclusion for damages caused by "constant or repeated seepage or leakage of water…over a period of 14 or more days." The application of this exclusion was discussed in the recent opinion of Hicks v. American Integrity Ins. Co. of Florida, 43 Fla. L. Weekly D446a (Fla. 5th DCA 2018). In this case, while the insured was out of town, the water line to his refrigerator started to leak. When the insured return home over a month later, the supply line was discharging almost a thousand gallons of water per day. The insured submitted a property insurance claim. The property insurer engaged a consultant that opined (likely, correctly) that the water line had been leaking for at least five weeks. Based on the above-mentioned exclusion, i.e., that water had been constantly leaking for over a period of 14 days, the insurer denied coverage. This denial led to the inevitable coverage dispute. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Real Estate & Construction News Roundup (2/21/24) – Fed Chair Predicts More Small Bank Closures, Shopping Center Vacancies Hit 15-year Low, and Proptech Sees Mixed Results

March 19, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, office occupancy rates hit all-time lows, global hotel investment to exceed numbers from 2023, federal courts look into real estate commissions, and more!

Federal Reserve chair Jerome Powell is predicting that more small banks will likely close or merge due to commercial real estate weaknesses. (David Hollerith, Yahoo)
An industry-shaking lawsuit making its way through the federal court system could upend the long-established way of paying commissions. (Jeff Ostrowski, Bankrate)
A good retail space is getting harder to find with the vacancy rate for shopping centers nationwide at a 15-year low. (Emily Peck, Axios)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

COLUMBUS OHIO BUILDING EXPERT DIRECTORY AND CAPABILITIES