Seattle Washington Building Expert Directory

Congratulations to Partner John O’Meara for Being Named as One of America’s Top 100 Civil Defense Litigators for Three Consecutive Years!

September 20, 2021 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Please join Bremer Whyte Brown & O’Meara, LLP in congratulating Woodland Hills Partner John O’Meara for being selected as one of America’s Top 100 Civil Defense Litigators for the third year in a row! Membership among America’s Top 100 Civil Defense Litigators highlights the accomplishments of the nation’s most esteemed and skilled Civil Defense attorneys. Only 100 attorneys in each state receive this honor and candidates for membership are identified through third-party research or peer nominations by America’s Top 100 or elite attorneys in the community. Candidates are judged by the attorney’s lifetime legal achievements, professional experience, significant case results, peer reputation, client satisfaction, other notable honors, media notoriety, and community impact. Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Appropriation Bill Cuts Military Construction Spending

June 15, 2011 — CDJ STAFF

The Hill reports that HR 2055, the Military Construction, Veterans Affairs (VA) and Related Agencies bill, has passed with only five votes in opposition. The bill cuts the budget for military construction spending by $2.6 billion due to anticipated base closures.

The bill includes $186 million for family housing construction by the Army, $100 million for family housing construction by the Navy and Marines, and $84 million for family construction by the Air Force, with an additional $50 million allocated for the DOD outside the military branches. By the act, these funds will remain available until September 30, 2016.

Read the full story…

Read HR 2055

Read the court decision
Read the full story...
Reprinted courtesy of

Flint Water Crisis and America’s Clean Water Access Failings

June 28, 2021 — Pam Radtke Russell - Engineering News-Record
Growing up on a Navajo reservation in Arizona, Jay Yazzie, now a senior environmental engineer at Brown and Caldwell, did not have running water in his home. To get its water supply, the family would take a 55-gallon drum to a livestock well or to a distribution point to obtain potable water for everyday use. He was 10 when his family was finally hooked up to a reliable supply. Reprinted courtesy of Pam Radtke Russell, Engineering News-Record Ms. Russell may be contacted at Russellp@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Quick Note: Independent Third-Party Spoliation Of Evidence Claim

June 18, 2019 — David Adelstein - Florida Construction Legal Updates
In an earlier posting I discussed the difference between first-party spoliation of evidence and third-party spoliation of evidence. There is NO independent cause of action for first-party spoliation of evidence because that can be dealt with directly in the underlying lawsuit. This deals with the assertion that an actual party to a lawsuit spoiled evidence. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Dispute Review Boards for Real-Time Dispute Avoidance and Resolution

August 20, 2019 — Neal J. Sweeney, Esq. - ConsensusDocs
The use of dispute tribunals generally referred to as Dispute Review Boards or DRBs on major projects has matured. Use of a DRB cannot guarantee elimination of post-project litigation, but when used properly, a DRB can be an enormously effective tool to avoid and resolve disputes rapidly and during construction. The modest out-of-pocket costs of a DRB can pay big dividends. DRBs offer the opportunity to shorten the life cycle of a dispute by requiring the principals to confront and address the merits of their dispute, rather than simply hunkering down and focusing on posturing and preparing for arbitration or litigation. Even when a DRB cannot immediately resolve a dispute, the process can still facilitate subsequent settlement and cost-effectively prepare both parties for formal adjudication. DRBs can also enhance communications and help the parties avoid and resolve problems before they spiral into disputes. DRBs were first and are most widely used on big civil and infrastructure projects, but the benefits of a DRB extend equally to major building projects, particularly hospitals, and industrial projects and should be used in those sectors. Read the court decision
Read the full story...
Reprinted courtesy of Neal J. Sweeney, Esq., Jones Walker LLP
Mr. Sweeney may be contacted at nsweeney@joneswalker.com

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Review your Additional Insured Endorsement

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
In his blog, Construction Contractor Advisor, Craig Martin explained the importance of reviewing your additional insured endorsement. Martin pointed out that in Mississippi, the “Fifth Circuit Court of Appeals recently ruled in Woodward, LLC v. Acceptance Indemnity Insurance Company, that a general contractor, named as an additional insured, did not have coverage for claims that a subcontractor performed faulty work.” The problem “was the language in the additional insured endorsement, which provided coverage for ongoing operations, not completed operations.” While Martin admitted that the case applies to Mississippi, he concluded that “the issue Midwestern readers should consider is the court’s conclusion that non-conformance with the plans, in essence a construction defect claim, arises from completed operations.” Read the court decision
Read the full story...
Reprinted courtesy of

Measure of Damages for a Chattel Including Loss of Use

November 16, 2020 — David Adelstein - Florida Construction Legal Updates
In a non-construction case, but an interesting case nonetheless, the Second District Court of Appeals talks about the measure of damages when dealing with chattel (property) including loss of use damages. Chattel, you say? While certainly not a word used in everyday language, a chattel is “an item of tangible movable or immovable property except real estate and things (such as buildings) connected with real property.” Equipment, machinery, personal items, furniture, etc. can be considered chattel. With respect to the measure of damages for a chattel:

“Where a person is entitled to a judgment for harm to chattels not amounting to a total destruction in value,” the plaintiff may make an election out of two theories of recovery in addition to compensation for the loss of use. Badillo v. Hill, 570 So. 2d 1067, 1068 (Fla. 5th DCA 1990) (quoting Restatement of Torts § 928 (Am. Law Inst. 1939)). In addition to compensation for the loss of use, the plaintiff may elect either “the difference between the value of the chattel before the harm and the value after the harm” or “the reasonable cost of repairs or restoration where feasible, with due allowance for any difference between the original value and the value after repairs.” Id. (quoting Restatement of Torts § 928).

Sack v. WSW Rental of Sarasota, LLC, 45 Fla.L.Weekly D2306a (Fla. 2d DCA 2020). Sack is a good example of a case dealing with the measure of damages with a chattel, here, an aircraft, including loss of use damages. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES