Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Reports of the Death of SB800 are Greatly Exaggerated – The Court of Appeal Revives Mandatory SB800 Procedures
September 03, 2015 —
Steven M. Cvitanovic & David A. Harris – Haight Brown & Bonesteel LLPIn a 20 page opinion, the Court of Appeal for the Fifth District repudiated the holding of Liberty Mutual Insurance Co. v. Brookfield Crystal Cove, LLC (2013) 219 Cal.App.4th 98 (“Liberty Mutual”), and held that plaintiffs in construction defect actions must comply with the statutory pre-litigation inspection and repair procedures mandated by SB800 (the “Act”) regardless of whether they plead a cause of action for violation of the Act. The Case, McMillin Albany LLC v. Superior Court (Carl Van Tassell), (Ct. of Appeal F069370) breathes new life into the Act’s right to repair requirements, and reinforces the Act’s stated purpose of seeking to limit the number of court cases by allowing a builder to resolve construction defect claims by agreeing to repair the homeowners’ residence.
In McMillin, 37 homeowners filed a lawsuit against McMillin, the builder of their homes, alleging eight causes of action, including strict products liability, negligence, and breach of express and implied warranty. Plaintiffs’ third cause of action alleged violations of the Act. The plaintiffs did not follow the Act’s notification procedures and filed their lawsuit without providing McMillin with an opportunity to repair the alleged defects. Plaintiffs and McMillin attempted to negotiate a stay of the lawsuit to complete the Act’s prelitigation procedures. When talks broke down, plaintiffs dismissed the third cause of action and contended they were no longer required to follow the Act’s prelitigation procedures. McMillin filed a motion to stay with the trial court. The trial court denied McMillin’s motion concluding that under Liberty Mutual, “[plaintiffs] were entitled to plead common law causes of action in lieu of a cause of action for violation of the building standards set out in [the Act], and they were not required to submit to the prelitigation process of the Act when their complaint did not allege any cause of action for violation of the Act.”
Reprinted courtesy of
Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and
David A. Harris, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com
Mr. Harris may be contacted at dharris@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Be a Good Neighbor: Techniques to Mitigate the Risk of Claims from Adjacent Landowners
December 07, 2020 —
Joshua Levy, Josh Neudorfer & Madeleine Bailey - Construction ExecutiveIn May 2020, a real estate developer performing excavation work in New York was sued by a neighboring property owner for property damage. A court overturned an injunction preventing the developer from continuing excavation work after reviewing a preconstruction assessment that showed the damage to the neighboring property was preexisting—not caused by the excavation (see Feldman v. 3588 Nostrand Ave. LLC as an example)
A preconstruction assessment is one of the most important tools in the arsenal of a developer protecting itself from neighbors bringing claims for property damage. Part two of this series will review the benefits of risk mitigation tools recommended for developers such as postconstruction assessments and monitoring during construction.
Preconstruction Assessment Overview
A preconstruction assessment is a review of a property adjacent to a site where demolition and/or construction activities are to take place. The goal of the assessment is to establish baseline conditions by conducting an inspection of buildings and infrastructure, including identification of existing damage to improvements, so that causation of any alleged damages can be more easily determined.
Reprinted courtesy of
Joshua Levy, Josh Neudorfer & Madeleine Bailey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Levy may be contacted at joshua.levy@huschblackwell.com
Mr. Neudorfer may be contacted at jneudorfer@thesigmagroup.com
Read the court decisionRead the full story...Reprinted courtesy of
California Court Invokes Equity to Stretch Anti-Subrogation Rule Principles
June 18, 2019 —
Gus Sara & William L. Doerler - The Subrogation StrategistIn Western Heritage Ins. Co. v. Frances Todd, Inc. 2019 Cal. App. Lexis 299, the Court of Appeals of California, First Appellate District, addressed whether a commercial condominium association’s carrier could subrogate against the tenants (aka lessees) of one of its member unit owners. After examining the condominium association’s declarations, as well as the lease terms between the owner and the lessees, the court held that the association’s carrier could not subrogate against the lessees because they were implied co-insureds on the policy. To reach its decision, the court explained that an insurer steps into the shoes of its insured, not the party with whom it is in privity. Although the first-party property portion of the association’s insurance policy did not, as required by the association’s declarations, have the owner listed as an additional named insured, the court held that it would be inequitable to treat the association as the sole insured for purposes of determining Western Heritage’s right to bring a subrogation action.
In Western Heritage, William R. de Carion d/b/a Surfwood Properties (de Carion or Lessor), owned a commercial unit within a multi-unit commercial building. The building was managed by the East Shore Commercial Condominiums Owners’ Association (the Association). As a unit owner, de Carion was a member of the Association. The Association’s Declarations of Codes, Covenants and Restrictions (CC&Rs) required the Association to procure fire insurance for the commercial units by adding the unit owners as additional named insureds. The CC&Rs also prohibited owners and their “tenants” from procuring their own fire insurance policies for the premises. In 2013, de Carion leased his commercial space to Frances Todd, Inc. d/b/a The Wooden Duck, Eric Todd Gellerman and Amy Frances Feber (Lessees).
Reprinted courtesy of
Gus Sara, White and Williams LLP and
William L. Doerler, White and Williams LLP
Mr. Sara may be contacted at sarag@whiteandwilliams.com
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Generally, What Constitutes A Trade Secret Is A Question of Fact
February 01, 2021 —
David Adelstein - Florida Construction Legal UpdatesIn construction, contractors maintain competitiveness by compiling, combining, utilizing, or developing proprietary and unique systems. The systems can be from a cost standpoint (determining general conditions or general requirement costs and percentages including percentages for insurance) or can be with respect to certain construction assembly or delegated design components. Such proprietary and unique systems are trade secrets to the contractors and efforts are taken to identify such information as confidential when proposing on a project. Contractors would not want such systems disclosed to others because it would dilute and impact what they believe is valuable and makes them competitive in the marketplace.
Florida’s Uniform Trade Secret Act (“FUTSA”) creates a statutory cause of action for the misappropriation of trade secrets. (FUTSA is set forth in Florida Statute s. 688.001 en seq.) FUTSA displaces or “preempts all claims [such as common law claims] based on misappropriation of trade secrets.” Alphamed Pharmaceuticals Corp. v. Arriva Pharmaceuticals, Inc., 391 F.Supp.2d 1148, 1167 (S.D.Fla. 2005). See also Fla. Stat. s. 688.008.
Florida Statute s. 688.002 (found here) defines the terms “trade secret” and “misappropriation.”
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Ex-Corps Worker Pleads Guilty to Bribery on Afghan Contract
July 26, 2017 —
Tom Ichniowski - Engineering News-RecordA former Army Corps of Engineers contracting official has pleaded guilty to a federal charge that he took $320,000 in bribes from a contractor in exchange for help on a U.S. road contract in Afghanistan, the Dept. of Justice says.
Read the court decisionRead the full story...Reprinted courtesy of
Tom Ichniowski, ENRMr. Ichniowski may be contacted at
ichniowskit@enr.com
Housing Starts in U.S. Slumped More Than Forecast in March
April 20, 2016 —
Sho Chandra – BloombergNew-home construction in the U.S. slumped more than projected in March, reflecting a broad-based retreat that showed the industry lost momentum heading into the busiest time of year.
Residential starts decreased 8.8 percent to a 1.09 million annualized rate that was the lowest since October and weaker than any forecast of economists surveyed by Bloomberg, Commerce Department data showed Tuesday in Washington. Permits, a proxy for future construction, also dropped.
Read the court decisionRead the full story...Reprinted courtesy of
Sho Chandra, Bloomberg
Exponential Acceleration—Interview with Anders Hvid
December 01, 2017 —
Aarni Heiskanen - AEC BusinessAnders Hvid is a Danish consultant, speaker, and author. He talks about digital disruption, exponential acceleration, and paradigm shifts that are taking place in a world that is moving from local and linear into global and exponential.
“I have a background in social studies. My interest is in humans, and systems in which they work together. I’ve always had a deep fascination with technology and how it influences our society, our jobs, our democracies, and systems,” Anders says. He visited Singularity University back in 2010, and that experience made a lasting impression on him. “It freaked me out, to be honest, and it opened my eyes to how important technology is.”
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
info@aepartners.fi