Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Hurricane Ian: Florida Expedites Road Work as Damage Comes Into Focus
October 10, 2022 —
Derek Lacey - Engineering News-RecordHurricane Ian’s devastation is coming into view days after the storm decimated southwest Florida. Work is underway to rebuild much of the state’s electrical, transportation and other infrastructure, with certain emergency road repairs expedited and restoration of power prioritized after the storm's devastation left millions in the dark and washed out roadways serving as the only access to barrier islands such as Sanibel Island and Pine Island.
Reprinted courtesy of
Derek Lacey, Engineering News-Record
Mr. Lacey may be contacted at laceyd@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Never, Ever, Ever Assume! (Or, How a Stuck Shoe is Like a Construction Project Assumption)
October 21, 2019 —
Melissa Dewey Brumback - Construction Law in North CarolinaThis summer, I had the fortune of taking a trip to Europe. The first place I visited was Amsterdam. A lovely town with a lot of culture and more canals than you can shake a stick at. I was meeting family there, but had hours to kill ahead of time. So, I decided to take the train from the airport into the City Centre, leave my bags at the train station luggage locker, and begin exploring.
My plan took its first misstep when I attempted to board the train. Not being in a hurry, I let the other passengers get on first. Sure, I noticed the train conductor blowing his whistle while I stepped onto the train, but figured I was fine since I was already on the steps up. Until, that is, the door began to close, with me in the doorway, suitcase in the train, one foot inside, and one foot mid step up to the cabin. The door closed on my backpack (which was still on my back), but I managed to force it into the train compartment. My shoe, however, was not quite as lucky. Part of my shoe made it inside, and part was outside the door.
No worry– just look for the door release mechanism, right? Wrong! There was none. The train started up, with my shoe still halfway in and halfway out of the train. (Luckily my foot itself made it inside all in one piece). The conductor came along to scold me, and told me that he could *probably* rescue my shoe once we got to Central Station. In the meantime, I sat on a nearby jump seat, keeping tabs on my shoe and fuming that this was *not* the way I planned to start my vacation. Long story short– the train conductor was able to salvage my shoe, but not without a lot of commentary on how I should never have boarded the train after the whistle blew. Lesson learned.
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Ragsdale Liggett PLLCMs. Brumback may be contacted at
mbrumback@rl-law.com
Terminating Notice of Commencement Without Contractor’s Final Payment Affidavit
October 23, 2018 —
David Adelstein - Florida Construction Legal UpdatesPrior to construction work being performed on your property, a Notice of Commencement should be recorded. Among other things, construction liens will relate back in time to an effective Notice of Commencement (meaning it has not expired). For this reason, lenders or others will want the Notice of Commencement to be terminated when the job is complete by recording in the official records a Notice of Termination of the Notice of Commencement. There is a statutory procedure to terminate a Notice of Commencement pursuant to Florida Statute 713.132.
Frequently, a clerk will want the Notice of Termination of the Notice of Commencement to be accompanied with a Contractor’s Final Payment Affidavit because 713.132 says, in material part:
(2) An owner has the right to rely on a contractor’s affidavit given under s. 713.06(3)(d), except with respect to lienors who have already given notice, in connection with the execution, swearing to, and recording of a notice of termination. However, the notice of termination must be accompanied by the contractor’s affidavit.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
New Jersey Rules that Forensic Lab Analysts Can’t be Forced to Testify
August 06, 2014 —
Beverley BevenFlorez-CDJ STAFFThe New Jersey Law Journal reported that the New Jersey Supreme Court has rejected a rule that would have required “laboratory analysts who prepare forensic reports in criminal cases be available for cross-examination at trial.”
The court stated that “requiring every analyst who was involved in the testing to be available for questioning by the defense was not required by the U.S. Constitution's Sixth Amendment Confrontation Clause and that doing so would create ‘practical drawbacks that range from moderate to severe.’”
Read the court decisionRead the full story...Reprinted courtesy of
Wisconsin Supreme Court Holds that Subrogation Waiver Does Not Violate Statute Prohibiting Limitation on Tort Liability in Construction Contracts
October 21, 2019 —
Gus Sara - The Subrogation StrategistIn Rural Mut. Ins. Co. v. Lester Bldgs., LLC 2019 WI 70, 2019 Wisc. LEXIS 272, the Supreme Court of Wisconsin considered whether a subrogation waiver clause in a construction contract between the defendant and the plaintiff’s insured violated Wisconsin statute § 895.447, which prohibits limitations of tort liability in construction contracts. The Supreme Court affirmed the lower court’s decision that the waiver clause did not violate the statute because it merely shifted the responsibility for the payment of damages to the defendant’s insurance company. The waiver clause did not limit or eliminate the defendant’s tort liability. This case establishes that while
§ 895.447 prohibits construction contracts from limiting tort liability, a subrogation waiver clause that merely shifts responsibility for the payment of damages from a tortfeasor to an insurer does not violate the statute and, thus, is enforceable.
In Rural Mutual, the plaintiff’s insured, Jim Herman, Inc. (Herman), entered into a contract with Lester Buildings, LLC (Lester) to design and construct a barn on Herman’s property. The contract included a provision that stated the following:
Both parties waive all rights against each other and any of their respective contractors, subcontractors and suppliers of any tier and any design professional engaged with respect to the Project, for recovery of any damages caused by casualty of other perils to the extent covered by property insurance applicable to the Work or the Project, except such rights as they have to the proceeds of such property insurance and to the extent necessary to recover amounts relating to deductibles of self-insured retentions applicable to insured losses. . . . This waiver of subrogation shall be effective notwithstanding allegations of fault, negligence, or indemnity obligation of any party seeking the benefit or production [sic] of such waiver.
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Vaccine Mandate Confusion Continues – CMS Vaccine Mandate Restored in Some (But Not All) US States
January 03, 2022 —
David S. Harvey, Jr. & Sarah Hock - Lewis BrisboisTampa, Fla. (December 16, 2021) - As has been widely publicized, the Biden Administration has attempted to impose various forms of vaccine mandates under a variety laws and programs. At the same time, we have seen a flurry of opposition to these efforts ranging from new state laws (for example, in Florida) to court challenges seeking to enjoin the effort.
One of the federal mandates was issued by the Centers for Medicare & Medicaid Services (CMS) and is applicable to staff at Medicare- and Medicaid-certified healthcare providers. Initially, fourteen states sued in opposition to the CMS mandate and were able to obtain a nationwide injunction issued by a federal district judge in Louisiana. That injunction was appealed to the Fifth Circuit Court of Appeals, which has now issued a decision that awards points to both sides.
The Fifth Circuit ruled the injunction only applies to the 14 states that participated in the Louisiana lawsuit and not nationwide. Those states are Alabama, Arizona, Georgia, Idaho, Indiana, Kentucky, Louisiana, Mississippi, Montana, Ohio, Oklahoma, South Carolina, Utah, and West Virginia. This opinion has the potential to revive the CMS vaccine mandate in just over half of U.S. states. We can anticipate new suits will be filed as to other states, with the outcome still uncertain. It is unknown at this point whether the United States Supreme Court will agree to review the issues when such review is sought in the near future.
Reprinted courtesy of
David S. Harvey, Jr., Lewis Brisbois and
Sarah Hock, Lewis Brisbois
Mr. Harvey may be contacted at David.Harvey@lewisbrisbois.com
Ms. Hock may be contacted at Sarah.Hock@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of
PA Supreme Court to Rule on Scope of Judges' Credibility Determinations
April 20, 2016 —
Max Kimbrough – White and Williams LLPIn IA Construction v. WCAB (Rhodes), the Commonwealth Court reversed the WCJ’s decision to deny the employer’s Modification Petition on the basis that the employer’s medical expert was not credible. In the underlying case, the claimant was determined to have sustained compensable work injuries to his head, neck and back. The employer subsequently filed a Modification Petition, seeking to modify benefits to Partial Disability based on an Impairment Rating Evaluation (IRE) which found that the claimant had a 34% whole body impairment. The WCJ ultimately denied the employer’s Modification Petition, finding that the IRE physician's categorization of the claimant's injuries and interpretation of the claimant's impairment level from his brain injury was not credible.
Read the court decisionRead the full story...Reprinted courtesy of
Max Kimbrough, White and Williams LLPMr. Kimbrough may be contacted at
kimbroughm@whiteandwilliams.com