Cambridge Massachusetts Building Expert Directory

Discussing Parametric Design with Shajay Bhooshan of Zaha Hadid Architects

May 10, 2017 — Aarni Heiskanen - AEC Business
obotics, 3D printing, and digital fabrication—these evolving technologies are changing how we design and construct. Looking into the future can surprisingly cause us to rediscover history, as I learned when discussing parametric design with Shajay Bhooshan. During the AEC Hackathon Munich in April 2017, I became acquainted with Shajay Bhooshan, associate at Zaha Hadid Architects. Shajay showed me designs that were intriguingly reminiscent of natural forms but completely modern in expression. He explained how these lightweight structures had been digitally designed and constructed with minimal use of material. One of the examples he shared was a large shell structure that consisted of aluminium elements that could be assembled and dismantled easily. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

Sioux City Building Owners Sue Architect over Renovation Costs

December 04, 2013 — CDJ STAFF
According to the architects, it should have cost a few hundred thousand dollars to strengthen the floors of Sioux City’s Badgerow Building. Instead, the upgrades cost somewhere between $3 and $5 million, which Mako One, the builder’s owners, said would have dissuaded them from starting had they known. Mako is suing M Plus Architects, for this and for its recommendation that the building’s windows be changed. That change ran foul of historic preservation guidelines, and the windows will have to be replaced. M Plus is, in return, suing Mako One over $150,000 in unpaid bills. Meanwhile, a data center is moving in on the fourth floor. Read the court decision
Read the full story...
Reprinted courtesy of

Judgment for Insured Upheld After Insurer Rejects Claim for Hurricane Damage

April 15, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court of Appeals affirmed a trial court's judgment as modified against Lloyds for improperly denying a claim for damage caused by Hurricane Ike. Nat'l Lloyds Ins. Co. v. Lewis, 2015 Tex. App. LEXIS 1573 (Tex. Ct. App. Feb. 19, 2015). Lewis sued Lloyds, alleging that, although her home and personal property were seriously damaged by Hurricane Ike, her claim was denied. At trial, Lloyds testified that the damage to Lewis' home had been previously caused by Hurricane Rita and Lloyds had already paid for repair of the roof. Nevertheless, Lewis had not used the payment for roof repairs. Lewis admitted that she used some of the payment after Hurricane Rita to purchase a generator and for evacuation expenses, but the majority of the payment was used for roof repairs. Lewis' expert engineer testified that the damage to Lewis' home was caused by wind and water intrusion through a hole caused by a tree limb that fell during Hurricane Ike. The expert further opined that the cost to mitigate the damage to the home and bring it up to livable standard was $156,155. Further, the home was a constructive total loss. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Techniques for Resolving Construction Disputes

September 16, 2019 — Jason Lambert - Construction Executive
With most construction projects involving dozens, if not hundreds, of companies and individuals, it is no surprise that conflicts arise that are not always able to be resolved on the jobsite. But these conflicts need not always reach the court room or cost thousands (or much more) to resolve. With some planning, contractors can build faster and less expensive dispute resolution options into their project so they can spend more time keeping the project moving and less time arguing over who is right. Even for modest-sized projects, a multi-tiered approached to dispute resolution can be helpful. As a first level of dispute resolution, consider requiring the relevant parties to attend informal or formal mediation. The benefits of even an informal mediation is that it can get stalemated parties to the table to talk again. Formal mediation adds the benefit of a neutral third-party who can help get talks moving or help antagonistic parties communicate. Further, mediation allows each side an opportunity to hear what the other side is looking for to resolve the dispute. Not only is this valuable in reaching a compromise, but it also gives each side an idea of what the other will bring to the table in any subsequent litigation. Finally, there are many ways to implement these procedures. General contractors can require pre-suit mediation with their subcontractors to resolve one-on-one disputes but should also consider requiring subcontractors to use pre-suit mediation to resolve disputes between subcontractors or between subcontractors and sub-subcontractors or material suppliers if the dispute threatens the progress at the project. Reprinted courtesy of Jason Lambert, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Avoid the Headache – Submit the Sworn Proof of Loss to Property Insurer

September 28, 2020 — David Adelstein - Florida Construction Legal Updates
Property insurance policies (first party insurance policies) contain post-loss obligations that an insured must (and should) comply with otherwise they risk forfeiting insurance coverage. One post-loss obligation is the insurer’s right to request the insured to submit a sworn proof of loss. Not complying with a post-loss obligation such as submitting a sworn proof of loss can lead to unnecessary headaches for the insured. Most of the times the headache can be avoided. Even with a sworn proof of loss, there is a way to disclaim the finality of damages and amounts included by couching information as estimates or by affirming that the final and complete loss is still unknown while you work with an adjuster to quantify the loss. The point is, ignoring the obligation altogether will result in a headache that you will have to deal with down the road because the property insurer will use it against you and is a headache that is easily avoidable. And, it will result in an added burden to you, as the insured, to demonstrate the failure to comply did not actually cause any prejudice to the insurer. By way of example, in Prem v. Universal Property & Casualty Ins. Co., 45 Fla. L. Weekly D2044a (Fla. 3d DCA 2020), the insured notified their property insurer of a plumbing leak in the bathroom. The insurer requested for the insured to submit a sworn proof of loss per the terms of the insured’s property insurance policy. The insurer follow-up with its request for a sworn proof of loss on a few occasions. None was provided and the insured filed a lawsuit without ever furnishing a sworn proof of loss. The insurer moved for summary judgment due the insured’s failure to comply with the post-loss obligations, specifically by not submitting a sworn proof of loss, and the trial court granted the insurer’s motion. Even at the time of the summary judgment hearing, the insured still did not submit a sworn proof of loss. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Wilke Fleury Celebrates the Addition of Two New Partners

February 18, 2019 — Wilke Fleury
Wilke Fleury celebrates the addition of two new partners – Shannon Smith-Crowley and Daniel J. Foster – who complement the firm’s shifting generations of leadership. Shannon and Danny bring unique perspective and excellent capability to Wilke Fleury’s partnership effective January 1, 2019. Shannon has been a registered lobbyist in California for 20 years. After a career in managed care, she started lobbying with the California Medical Association before founding her own firm, Partners In Advocacy to specialize in medical and reproductive health advocacy. At Wilke Fleury, her areas of practice include health care, women’s equity, life sciences, the biomedical industry, new family formation and emerging technologies in green energy. After a four year tenure with the firm, she has been elevated to the partnership. Click here to read more about Shannon Smith-Crowley. Daniel Foster’s litigation practice is composed of matters involving complex construction defect litigation, mechanics liens claims, stop notice actions and Miller Act claims. He represents clients before the Contractors State License Board and handles matters involving breach of warranty, the Song-Beverly Consumer Warranty Act, indemnity agreements and liability insurance coverage. Click here to read more about Daniel J. Foster Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury

Federal Energy Regulator Approves Rule to Speed Clean Energy Grid Links

August 28, 2023 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
The Federal Energy Regulatory Commission unanimously passed a sweeping rule at its July 27 open meeting meant to eliminate U.S. transmission system bottlenecks for new power generation and storage. But stakeholders worry that more needs to be done to add needed and viable clean energy projects to the grid. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record ENR may be contacted at enr@enr.com Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES