Preparing For and Avoiding Residential Construction Disputes: For Homeowners and Contractors
September 18, 2023 —
Christopher G. Hill - Construction Law MusingsFor this week’s Guest Post Friday here at Construction Law Musings, we welcome a great friend. Scott Wolfe Jr. (@scottwolfejr)is a construction attorney in Louisiana, Washington and Oregon, and is the founding member of the construction practice Wolfe Law Group. He authors the Construction Law Monitor. He is also the founder of the mechanic lien and preliminary notice filing service, Zlien, and the author of its Construction Lien Blog.
Residential construction disputes come in all shapes and sizes, but very typically have one thing in common: they can get very nasty.
This is understandable, especially in today’s economy. The homeowner is spending hard-earned money on something very personal to them, their home. They want it done right. The contractor is working on really tight margins, and with a diligent client.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Presenting a “Total Time” Delay Claim Is Not Sufficient
September 12, 2022 —
David Adelstein - Florida Construction Legal UpdatesWhen presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss.
In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Think Twice Before Hedging A Position Or Defense On A Speculative Event Or Occurrence
July 13, 2020 —
David Adelstein - Florida Construction Legal UpdatesSometimes, hedging a position on a potential occurrence is not prudent. Stated differently, hedging a position on a contingent event is not the right course of action. The reason being is that a potential occurrence or contingent event is SPECULATIVE. The occurrence or event may not take place and, even if it does take place, the impact is unknown.
An example of hedging a defense on such a potential occurrence or contingent event can be found in a construction dispute involving a federal project out of the Eastern District of Virginia, U.S. f/u/b/o Champco, Inc. v. Arch Insurance Co., 2020 WL 1644565 (E.D.Va. 2020). In this case, the prime contractor hired a subcontractor to perform electrical work, under one subcontract, and install a security system, under a separate subcontract. The subcontractor claimed it was owed money under the two subcontracts and instituted a lawsuit against the prime contractor’s Miller Act payment bond. The prime contractor had issued the subcontractor an approximate $71,000 back-charge for delays. While the subcontractor did not accept the back-charge, it moved for summary judgment claiming that the liability for the back-charge can be resolved at trial as there is still over $300,000 in contract balance that should be paid to it. The prime contractor countered that the delays caused by the subcontractor could be greater than $71,000 based on a negative evaluation in the Contractor Performance Assessment Reporting System (“CPARS”). A negative CPARS rating by the federal government due to the delays caused by the subcontractor would result in a (potential) loss of business with the federal government (i.e., lost profit) to the prime contractor. The main problem for the prime contractor: a negative CPARs rating was entirely speculative as there had not been a negative CPARs rating and, even if there was, the impact a negative rating would have on the prime contractor’s future business with the federal government was unknown. To this point, the district court stated:
In this case, [prime contractor’s] claim for damages is wholly speculative. [Prime contractor] has not produced any evidence that its stated condition precedent—a negative CPARS rating—will actually occur and will have a negative impact on its future federal contracting endeavors. Specifically, [prime contractor] has not identified any facts that indicate that it will be subject to a negative CPARS rating or any indication of the Navy’s dissatisfaction with its work as the prime contractor on the Project… Further, a CPARS rating is only one aspect taken into consideration when federal contracts are awarded. In sum, there is no evidence of the following: (1) a negative CPARS rating issued to [prime contractor]; (2) [prime contractor’s] hypothetical negative rating will be the result of the delay [prime contractor] alleges was caused by [subcontractor]; or (3) [prime contractor’s] hypothetical negative CPARS rating will result in future lost profits.
U.S. f/u/b/o Champco, Inc., supra, at *2 (internal citation omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
New Jersey School Blames Leaks on Construction Defects, May Sue
January 28, 2013 —
CDJ STAFFThe Carlstadt Board of Education recently commissioned a investigation into the water leaks at Carlstadt Public School. The report has not been released in full, but redacted board minutes make reference to "a lack of waterproofing, drainage and clogged or buried weep holes." The investigation is ongoing and the board's business administrator, Pamela Baxley, states that its "ability to recover damages in potential litigation may be impacted should this information be released prior to the conclusion of their investigation."
The building in question opened in April 2007, and the leaking began that October. The contractor has fixed leaks, but further leaks have occurred.
Read the court decisionRead the full story...Reprinted courtesy of
No Duty to Defend Suit That Is Threatened Under Strict Liability Statute
July 09, 2014 —
Tred R. Eyerly – Insurance Law HawaiiThe Washington Court of Appeals found there was no duty to defend the insured under a strict liability statute for alleged contamination when no action was threatened by the agency. Gull Indus., Inc. v. State Farm Fire and Cas. Co., 2014 Wash. App. LEXIS 1338 (Wa. Ct. App. June 2, 2014).
Gull leased a gas station to the Johnsons from 1972 to 1980. In 2005, Gull notified the Department of Ecology (DOE) that there had be a release of petroleum product at the station. DOE sent a letter acknowledging Gull's notice of suspected contamination. In 2009, Gull tendered its defense to its insurer, Transamerica Insurance Group. Gull also tendered its claims as an additional insured to the Johnson's insurer, State Farm. Neither insurer accepted the tenders.
Gull then sued the insurers, arguing they had a duty to defend. Gull contended that because the state statute imposed strict liability, the duty to defend arose whether or not an agency had sent any communications about the statute or cleanup obligations. The insurers moved for partial summary judgment. The trial court ruled in favor of the insurers.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Bank Sues over Defective Windows
July 31, 2013 —
CDJ STAFFThe Federal Reserve Bank of St. Louis replaced 498 windows in its building in 2008. According to a consultant, they all have to be replaced again. The bank estimates that the damages will exceed $1.5 million, and they are suing the contractor who installed them, the window manufacturer, and others.
The windows were replaced to provide greater blast protection. But in 2011, the bank found that the special glass used was beginning to delaminate. The Federal Reserve is seeking to have all of the windows replaced “with windows that meet the specifications of the contract.”
McCarthy Building Construction says that it is attempting to resolve things. The contractor noted that it is “continuing to work with the Federal Reserve and other parties and hope we can resolve this matter in a timely manner.”
Read the court decisionRead the full story...Reprinted courtesy of
Free Texas MCLE Seminar at BHA Houston June 13th
May 29, 2014 —
Beverley BevenFlorez-CDJ STAFFThere are just two weeks remaining to sign up for Bert L. Howe & Associate’s next Texas MCLE seminar, THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION.
This activity will be presented on Friday, June 13th at noon, at BHA’s Houston offices, located at:
800 Town & Country Blvd.
Suite 300
Houston, TX 77024
There is no cost for attendance at this seminar and lunch will be provided.
This course has been approved for Minimum Continuing Legal Education credit by the State Bar of Texas Committee on MCLE in the amount of 1.0 credit hours, of which 0.0 credit hours will apply to legal ethics/professional responsibility credit. The seminar will be presented by Don MacGregor, general contractor and project manager.
Water intrusion through doors, windows and roofing systems, as well as soil and foundation-related movement, and the resultant damage associated therewith, are the triggering effects for the vast majority of homeowner complaints today and serve as the basis for most residential construction defect litigation. The graphic and animation-supported workshop/lecture activity will focus on the residential construction process from site preparation through occupancy, an examination of associated damages most often encountered when investigating construction defect claims, and the inter-relationships between the developer, general contractor, sub trades and design professionals. Typical plaintiff homeowner/HOA expert allegations will be examined in connection with those building components most frequently associated with construction defect and claims litigation.
The workshop will examine:
*Typical construction materials, and terminology associated with residential construction
*The installation process and sequencing of major construction elements, including interrelationship with other building assemblies
*The parties (subcontractors) typically associated with major construction assemblies and components
*An analysis of exposure/allocation to responsible parties.
Attendance at THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION seminar will provide the attendee with:
*A greater understanding of the terms and conditions encountered when dealing with common construction defect issues
*A greater understanding of contractual scopes of work encountered when reviewing construction contract documents
*The ability to identify, both quickly and accurately, potentially responsible parties
*An understanding of damages most often associated with construction defects, as well as a greater ability to identify conditions triggering coverage
Course #: 901290467 / Sponsor #: 14152. To register for the event, please email Don MacGregor at dmac@berthowe.com. If you have any questions, please feel free to contact Don at (800) 482-1822 (office) or (714) 713-4956 (cell).
Read the court decisionRead the full story...Reprinted courtesy of
Lakewood First City in Colorado to Pass Ordinance Limiting State Construction Defect Law
October 15, 2014 —
Beverley BevenFlorez-CDJ STAFFThe Denver Post reported that the Lakewood City Council passed an ordinance “designed to soften the effects of Colorado's controversial construction-defects law.” Specifically, the ordinance “gives developers and builders a ‘right to repair’ defects before facing litigation and would require condominium association boards to get consent from a majority of homeowners — rather than just the majority of the board — before filing suit.”
Not all residents are in favor of the ordinance. "It protects builders and big business at the expense of homeowners," Chad Otto, former president of the Grant Ranch homeowners association, told the crowd, as quoted by the Denver Post. "Does Lakewood want to be known as the mecca of poorly built condos?"
Proponents of the measure, including Lakewood Mayor Bob Murphy, claim that “Colorado's defects law…has forced up insurance premiums on new condo projects to the point where they are no longer feasible to build.” Furthermore, according to the Denver Post, “Condos represented only 4.6 percent of total new home starts in metro Denver in the second quarter of 2014, versus more than 26 percent in 2008, according to Metrostudy.”
Read the court decisionRead the full story...Reprinted courtesy of
