Seattle Washington Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Policy Language Matters: New Jersey Court Bars Cleanup Coverage Under Broad Policy Terms

May 15, 2023 — Stacy M. Manobianca - Saxe Doernberger & Vita, P.C.
The New Jersey Appellate Division in Handy & Harman v. Beazley USA Services, Inc., provided clarity regarding the interpretation of the Prior or Pending Litigation Exclusion in a site-specific environmental liability insurance policy. In Handy & Harman, the Appellate Division affirmed the trial court’s determination that the insurer was not required to defend or indemnify its policyholder, a metal etching company. The court held that the Prior or Pending Litigation Exclusion (which applied to prior litigation and prior claims) barred coverage for natural resource damages sought in the current litigation because (1) an Administrative Consent Order (“ACO”) is a claim; and (2) the underlying lawsuit was based on the same environmental contamination as addressed in the ACO.1 Read the court decision
Read the full story...
Reprinted courtesy of Stacy M. Manobianca, Saxe Doernberger & Vita, P.C.
Ms. Manobianca may be contacted at SManobianca@sdvlaw.com

Auditor: Prematurely Awarded Contracts Increased Honolulu Rail Cost by $354M

February 11, 2019 — Honolulu Star-Advertiser - Engineering News-Record
Jan. 10 --A series of "prematurely" awarded rail contracts doled out to construction companies as early as 2009 prompted delay claims and change orders that increased the cost of the Honolulu rail project by more than $354 million , according to a new report by the Hawaii State Auditor released today. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Manhattan Luxury Condos Sit on Market While Foreign Buyers Wait

January 21, 2015 — Prashant Gopal, Oshrat Carmiel and John Gittelsohn – Bloomberg
Manhattan real estate agent Lisa Gustin listed a four-bedroom Tribeca loft for $7.45 million in October, expecting a quick sale. Instead, she cut the price this month by $550,000. “I thought for sure a foreign buyer would come in,” said Gustin, a broker at Brown Harris Stevens who is still marketing the 3,800-square-foot (353-square-meter) apartment at 195 Hudson St. “So many new condos are coming up right now. They’ve been building them for the past few years and now they’re really hurting the resales.” Mr. Gopal may be contacted at pgopal2@bloomberg.net; Ms. Carmiel may be contacted at ocarmiel1@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Oshrat Carmiel and John Gittelsohn, Bloomberg

Do Not Lose Your Mechanics Lien Right Through a Subordination Agreement

December 21, 2020 — William L. Porter - Porter Law Group
If you are a member of the California construction industry you might know that the right of a contractor, subcontractor or supplier to record a mechanics lien to protect the right to payment is well protected by state law. In fact, our California Constitution, article XIV, Sec. 3 specifically elevates the right to a mechanics lien to “Constitutional right”. The right to a mechanics lien is further protected by a statutory framework, including Civil Code sec. 8122 which states:

“An owner, direct contractor, or subcontractor may not, by contract or otherwise, waive, affect, or impair any other claimant’s rights under this part, whether with or without notice, and any term of a contract that purports to do so is void and unenforceable unless and until the claimant executes and delivers a waiver and release under this article.”

Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Construction Litigation Roundup: “Hold the Pickles, Hold the Lettuce?”

October 02, 2023 — Daniel Lund III - Lexology
Hold the pickles, hold the lettuce? You can even hold the service… or at least proof of it! In a dispute over the construction of a Burger King restaurant in Tupelo, Mississippi, a state court suit by the owner against its general contractor and architect was removed to federal court by one of the defendant parties, on the basis of the diversity of citizenship of the defendant parties from the plaintiff, per 28 U.S.C. § 1331(a). For its part, plaintiff, upon achieving service of its state court complaint against the various defendants, filed a proof of service as to the party which sought to remove the case, but not as to the other defendants (even though the other defendants were served). Once the case was removed to federal court and after the deadline for removal has passed, plaintiff sought to have the matter remanded based on the lack of the consent of the entirety of the defendant group to the removal, in accordance with 28 U.S.C. § 1446 (“When a civil action is removed solely under section 1441(a), all defendants who have been properly joined and served must join in or consent to the removal of the action.”). Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

$24 Million Verdict Against Material Supplier Overturned Where Plaintiff Failed to Prove Supplier’s Negligence or Breach of Contract Caused an SB800 Violation

November 21, 2017 — Jon A. Turigliatto, Esq. & Chelsea L. Zwart, Esq. – Chapman Glucksman Dean Roeb & Barger Bulletin
Originally published by CDJ on March 16, 2017 Acqua Vista Homeowners Assoc. v. MWL Inc. (2017) 2017 WL 371379 COURT OF APPEAL EXTENDS GREYSTONE HOMES, INC. v. MIDTEC, INC., HOLDING THAT CIVIL CODE §936 CREATES A NEGLIGENCE STANDARD FOR CLAIMS AGAINST MATERIAL SUPPLIERS BROUGHT UNDER SB800. The Fourth District California Court of Appeal recently published its decision Acqua Vista Homeowners Assoc. v. MWI, Inc. (2017) 2017 WL 371379, holding that claims against a material supplier under SB800 (Civil Code §895 and §936) require proof that the SB800 violation was caused by the supplier's negligence or breach of contract. Civil Code §936 states in relevant part, that it applies "to general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals to the extent that the general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals caused, in whole or in part, a violation of a particular standard as the result of a negligent act or omission or a breach of contract .... [T]he negligence standard in this section does not apply to any general contractor, subcontractor, material supplier, individual product manufacturer, or design professional with respect to claims for which strict liability would apply." Reprinted courtesy of Jon A. Turigliatto, Esq., Chapman Glucksman Dean Roeb & Barger and Chelsea L. Zwart, Esq., Chapman Glucksman Dean Roeb & Barger Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com Ms. Zwart may be contacted at czwart@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

California Clarifies Its Inverse Condemnation Standard

December 30, 2019 — Gus Sara - The Subrogation Strategist
In City of Oroville v. Superior Court, 446 P.3d 304 (Cal. 2019), the Supreme Court of California considered whether the City of Oroville (City) was liable to a dental practice for inverse condemnation damages associated with a sewer backup. The court held that in order to establish inverse condemnation against a public entity, a property owner must show that an inherent risk in the public improvement was a substantial cause of the damage. Since the dental practice did not have a code-required backwater valve — which would have prevented or minimized this loss — the court found that the city was not liable because the sewage system was not a substantial cause of the loss. This case establishes that a claim for inverse condemnation requires a showing of a substantial causal connection between the public improvement and the property damage. It also suggests that comparative negligence can be a defense to inverse condemnation claims. In December 2009, a dental practice, WGS Dental Complex (WGS), located in the City, incurred significant water damage as a result of untreated sewage from the City’s sewer main backing up into WGS’ building. WGS submitted a claim to its insurance carrier, The Dentists Insurance Company (TDIC) and, in addition, sued the City for its uninsured losses, alleging inverse condemnation and nuisance. TDIC joined the litigation, alleging negligence, nuisance, trespass and inverse condemnation. Under California law, when a government entity fails to recognize that an action or circumstance essentially amounts to a taking for public use, a property owner can pursue an inverse condemnation action for compensation. The City filed a cross-complaint against WGS for failing to install a code-required backwater valve on their lateral sewer line, which would have prevented or minimized the backup. The City filed a motion for summary judgment, which the trial court denied. WGS then sought a judicial determination on the issue of inverse condemnation. The City presented evidence that the sewage system was designed in accordance with industry standards, and that WGS failed to comply with the City’s plumbing code by failing to install a backwater valve on its private sewer lateral. The trial court found the City liable for inverse condemnation because the blockage that caused the backup originated in the City’s sewer line. The court held that the blockage was an inherent risk of sewer operation. The Court of Appeals affirmed the decision, holding that the City would have had to prove that the WGS’s lack of a backwater valve was the sole cause of the loss in order to absolve itself of liability. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES