Fairfield Connecticut Building Expert Directory

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

NIBS Consultative Council Issues Moving Forward Report on Healthy Buildings

July 25, 2021 — National Institute of Building Sciences
(WASHINGTON, DC, July 13, 2021) – The National Institute of Building Sciences Consultative Council has issued its 2020 Moving Forward Report, looking closely at the importance of healthy buildings. The report examines how buildings can protect and promote public health, providing recommendations for President Biden and policymakers on three components of healthy buildings: indoor environmental quality, the importance of design in promoting health, and promoting knowledge transfer between building owners and public health officials. “Ensuring that the spaces where we live and work are healthy and safe for continued occupancy is critical to overcoming the pandemic,” said Lakisha A. Woods, CAE, President and CEO of NIBS. “This is a fundamental pillar of public health and community resilience. The concept of healthy buildings goes well beyond continual sanitation of a building’s indoor environment to eliminate pathogens.” About NIBS National Institute of Building Sciences brings together labor and consumer interests, government representatives, regulatory agencies, and members of the building industry to identify and resolve problems and potential problems around the construction of housing and commercial buildings. NIBS is a nonprofit, non-governmental organization. It was established by Congress in 1974. For more information, visit nibs.org or follow @bldgsciences on Twitter and Facebook. Read the court decision
Read the full story...
Reprinted courtesy of

Third Circuit Holds That Duty to Indemnify "Follows" Duty to Defend

December 27, 2021 — Jeffrey J. Vita - Saxe Doernberger & Vita, P.C.
In a win for policyholders, the Third Circuit Court of Appeals recently affirmed a District Court’s 2018 ruling, which held that the duty to indemnify follows the duty to defend where a settlement precludes a determination on the facts of the case relative to liability and apportionment. In Liberty Mutual Insurance Co. v. Penn National Mutual Casualty Insurance Co.,1 a large concrete panel collapsed and killed a construction worker at a construction site in New Kensington, Pennsylvania. Cost Company (“Cost”), Liberty Mutual’s insured, was a masonry subcontractor on the project and had further subcontracted with Pittsburgh Flexicore Co. (“Flexicore”), Penn National’s insured, for the concrete panels. Cost’s subcontract agreement required Flexicore to name Cost as an additional insured under its general liability policy issued by Penn National. When the construction worker’s widow filed a wrongful death lawsuit against Cost and Flexicore, Cost demanded that Penn National defend and indemnify it as an additional insured under the policy. Penn National refused, arguing that any additional insured status had terminated at the conclusion of Flexicore’s work for Cost. As a result, Liberty Mutual defended Cost in the lawsuit, which was ultimately settled. Read the court decision
Read the full story...
Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C.
Mr. Vita may be contacted at JVita@sdvlaw.com

The Texas Supreme Court Limits the Use of the Economic Loss Rule

September 03, 2014 — Beverley BevenFlorez-CDJ STAFF
According to David Fisk of Kane Russell Coleman & Logan PC, in an article published by JD Supra Business Advisor, “[T]he Texas Supreme Court issued a per curium opinion limiting the application of the economic loss doctrine or rule, as it is referred to in Texas, in the context of residential construction defect claims.” In Chapman Custom Homes, Inc. v Dallas Plumbing Co., the court “ruled that a plumbing subcontractor assumes an implied duty not to flood or otherwise damage a home while performing its contract with a builder” and that “the economic loss rule does not apply in this context.” Read the court decision
Read the full story...
Reprinted courtesy of

Does Stricter Decertification Mean More “Leedigation?”

August 04, 2015 — Christopher G. Hill – Construction Law Musings
Recently, my friend and fellow construction attorney/consultant, Chris Cheatham (@chrischeatham) posted the news that USGBC will be more stringent on the de-certification front. This statement relates to the continued energy performance of LEED certified buildings and increases the likelihood that energy performance (as opposed to mere reporting) could lead to de-certification. I have discussed on several occasions the potential legal risks relating to green building. One of the big potential sources for such litigation (or “leedigation” as coined by Mr. Cheatham) is the possible de-certification of a previously certified building. With this latest statement by USGBC the specter of such de-certification seems even stronger. Couple this potential with the fact that anyone can challenge the certification of a building at any time and contractors, subcontractors and other construction professionals face potential liability for the performance of a building in ways well beyond their control. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Home Building on the Upswing in Bakersfield

May 10, 2013 — CDJ STAFF
Low inventories and low mortgage rates are leading developers to build new homes in Bakersfield, California. According to KGET, home permits are up forty-five percent over last April. In one development, a street of six homes all sold on the same day. Indications are also that people who lost their homes during the bust are entering homeownership again. Prices are also up. A year ago, the average home sale price was $145,000. Now it’s $250,000. Oh, and that development where they sold six homes in a day? The next phase of development goes on sale in May. Read the court decision
Read the full story...
Reprinted courtesy of

Pennsylvania Supreme Court Will Not Address Trigger for DEP Environmental Cleanup Action at This Time

August 14, 2018 — Gregory Capps - White and Williams LLP
On July 18, 2018, in Pennsylvania Manufacturers’ Association Insurance Company v. Johnson Matthey, Inc., et al., No. 24 MAP 2017 (Pa. July 18, 2018), the Pennsylvania Supreme Court quashed the Pennsylvania Manufacturers’ Association’s (PMA) appeal seeking review of a ruling denying its motion for summary judgment for an order that coverage for the cleanup of a toxic waste site is limited to the policy in effect when property damage was first discovered. In short, the court found the lower court’s ruling only narrowed the dispute between the parties and is, therefore, interlocutory and not appealable at this time. Read the court decision
Read the full story...
Reprinted courtesy of Gregory Capps, White & Williams LLP
Mr. Capps may be contacted at cappsg@whiteandwilliams.com

Remodels Replace Construction in Redding

September 09, 2011 — CDJ STAFF

The Record Searchlight reports that while new construction is down in Redding, California, residential and commercial remodel permits are up 17 percent. By August 2010, there had been 63 housing and commercial business starts in Redding, while this year has seen only 15.

One such remodel, that of Parkview Market, will cost about $201,000. Safeway is planning on two $80,000 remodels of its grocery stores in Redding. In all, the 150 building permits for remodels are worth a total of $2.8 million.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES